view Reasons for Judgment dismissing the Appeal

Transcription

view Reasons for Judgment dismissing the Appeal
COURT OF APPEAL FOR BRITISH COLUMBIA
Citation
A & G lnvestment lnc. v. 0915630 B.C
Ltd.,
2014 BCCA 425
Date: 20141104
Docket: C4041 193
Between:
A&Glnvestmentlnc.
Appellant
(Plaintiff)
And
0915630 B.C. Ltd.
Respondent
(Defendant)
Before:
The Honourable Mr. Justice Donald
The Honourable Madam Justice Bennett
The Honourable Mr. Justice Goepel
On appeal from: An order of the Supreme Court of British Columbia, dated
September 27,2013 (,4 & G lnvestment lnc. v. 0915630 B.C. Ltd.,2013 BCSC 1784,
Vancouver Docket No. S132980).
Counsel for the Appellant:
Counsel for the Respondent:
J.M. Webster, Q.C.
G.E. Sourisseau, LE. Shieh
Place and Date of Hearing:
Vancouver, British Columbia
September 8,2014
Place and Date of Judgment:
Vancouver, British Columbia
November 4,2014
Written Reasons by:
The Honourable Mr. Justice Goepel
Concurred in by:
The Honourable Mr. Justice Donald
The Honourable Madam Justice Bennett
A & G lnvestment lnc. v.0915630 B.C. Ltd.
Page 2
Summary:
The appellant, A & G lnvestment Inc., (fhe 'Purchaser) contracted with the
respondent, 0915630 B.C. Ltd. (Íhe 'Se//e/), to purchase 31 lots of a proposed
34 lot subdivision for $9,000,000. lt put down a deposit of $620,000. The contract
provided that conveyance would not complete untilthe 31 lots were in a 'ready-tobut'/d"state. The lots were not ready by December 18, 2012, the specified
completion date. The Purchaser eventually commenced this action for return of the
deposit. It was heard by way of summary trial. The chambers judge found that the
non-completion was not grounds for automatic termination of the contract. He also
found that the Purchaser expressed a clear intention not to pertorm the contract,
which constituted an anticipatory breach and a repudiation of the contract.
Held: Appealdismissed. The appeal turns on the proper interpretation to be given to
the contract. The clause in respect of the December 18, 2012 completion date does
not provide for automatic termination. The Purchaser could have elected to treat the
non-completion as a fundamental breach. lt did not do so in a timely manner. lt
cannot rely on a December 18, 2012 breach on April 23, 2013 as a fundamental
breach.
Reasons for Judgment of the Honourable Mr. Justice Goepel:
INTRODUCTION
11l
The appellant, A & G lnvestment lnc. (the "Purchaser") entered into an
agreement with the respondent, 0915630 B.C. Ltd. (the "Seller")for the purchase
and sale of 31 of 34 building lots to be created by way of a subdivision by the
Purchaser of three parcels of land located in Surrey, British Columbia (the
"Contract"). The purchase price was $9,000,000. The sale did not complete as
specified on December 18, 2012. On April 25,2013, the Purchaser brought an
action for the return of its $620,000 deposit.
l2l
The matter was heard by way of summary trial for three days before
Mr. Justice Leask. He dismissed the Purchaser's action. The Purchaser now
appeals.
BACKGROUND
t3l
On April 13,2012, the parties entered into the Contract. The relevant portions
of the Contract provide as follows:
A & G lnvestment lnc. v.0915630 B.C. Ltd.
3.
DEPOSIT: A non-refundable deposit of $620,000.00 which will form
part of the purchase price, will be paid directly to the seller upon
acceptance of the Contract.
4.
COMPLETION DATE AND CONDITION PRECEDENT: The Buyer
shall complete the purchase of the Propedy on the earlier of:
(a)
(b)
December 18,2012, or
the 21"1 day after the seller delivers written notice to the Buyer,
by way of regular mail to the address of the Buyer as set out
on page 1 of the Contract (which notice shall be deemed to be
received on the third day following the date of mailing) or
personal delivery to the Buyer, notifying the Buyer that:
(i)
(ii)
the Subdivision Plan has been filed with L.T.O.;
(iii)
the City will accept applications for a building permit for
the Property;
(iv)
the lots are ready to build and Lot grading Plans have
been registered at City of Surrey.
that the Seller has successfully concluded its preconstruction meeting with the Engineering Department
of the City in respect of the Subdivision Servicing
hereinafter defined; and
provided that in the event that the L.T.O. is not open for
business on such day, then the Completion Date shall be the
next Business Day,
(the "Gompletion Date").lt is a condition precedent (the "Condition
Precedent") of this Contract that items (b) (i), (ii), (iii) and (iv) above
will be completed prior to the Completion Date, subject to extensions
to the Completion Date pursuant to paragraph 5 and 6. ln the event
that the Condition Precedent has not been met by the later of
December 31,2013 (the "End Stop Date"), or such other revised
Completion Date pursuant to paragraph 5 and 6, the Contract shall
come to an end, the Deposit shall be refunded to the Buyer and
neither party will have any fudher obligation to the other.
5.
Page 3
EXTENSION OF COMPLETION DATE: Notwithstanding the
foregoing, the Seller may, at its option, exercisable by notice to the
Buyer or the Buyer's solicitor or notary, elect to extend the Completion
Date for up to 270 days (the "Extension Option"). ln the event that
the Seller exercised its Extension Option, then the Completion Date
shall be extended to be the date set out by the Seller, at its sole
discretion, as the Completion Date, provided that the Buyer shall be
given seven (7) days notice of the said date. The padies acknowledge
that the extension set out in this paragraph 5 shall be in addition to
any extension pursuant to paragraph 6 below and whether or not any
delay described in paragraph 6 has occurred.
A & G lnvestment Inc. v.0915630 B.C. Ltd.
l4l
I
SUBDIVISION: The Seller shall cause the Subdivision of the Parent
Parcels because of the filing of the Subdivision Plan to create the
Property.
26
TIME: Time will be of the essence. ln the event the Buyer fails to
complete the purchase of the Property, the Deposit paid by the Buyer
will be absolutely forfeited to the Seller in accordance with the Rea/
Estate Development Marketing Act, on account of damages, without
prejudice to the Seller's other remedies.
Page 4
The Purchaser paid the deposit of $620,000 directly to the Seller on
April 13,2012.
tsl
From the time the Contract was made in April 2012 through to March 2013,
the Purchaser undertook marketing activities to resell the lots it was purchasing.
By March 2013 the Purchaser had found buyers for only seven of the 31 lots.
t6l
The Contract required the Seller to file the subdivision plan and complete the
other steps set out in clauses a(bXi)-(¡v) of the Contract prior to the completion date
(the "Conditions Precedent"). lt was the Seller's responsibility to complete those
steps. The conveyance would not complete until the 31 lots were in a "ready-tobuild" state.
l7l
By April 2012, the Seller had received a preliminary letter of approval from the
City of Surrey for its subdivision plan. The Seller's contractor could not begin the
work required to prepare the land until the subdivision plan passed fourth reading at
the City. Fourth reading was not obtained until late November 2012.
l8l
By November 2012, through no fault of the Seller, the lots had not yet been
created and were not in a "ready-to-build" state. The Seller notified the Purchaser's
agent that the lots would not be ready for the December 18,2012 completion date
and that completion would be delayed until about April 2013. The Seller did not,
however, exercise its option to extend the completion date.
tgl
Mr. Kumar, the principal of the Purchaser, deposed that he knew in advance
of December 18, 2012 that the Contract would not close that day. He testified that he
A & G lnvestment lnc. v. 0915630 B.C. Ltd.
5
did not know the legal status of the subdivision at that time but expected that the
Seller would proceed with the subdivision as it was required to under the Contract.
Neither party took any steps with respect to the December 18,2012 completion
date.
[10] After December 18, 2012, both the Purchaser
and Seller continued to act as if
the Contract was alive. The Seller continued to take the steps necessary to fulfill the
Conditions Precedent. The Purchaser continued to market the lots to third parties.
t11]
Subsequent to the subdivision passing fourth and final reading, meetings took
place between the Seller's engineers, its contractor and representatives from the
City's engineering department. The contractor was not given the final papenruork it
needed to begin physical work on the site until late January or early February 2013.
U2l
ln January 2013 the subdivision plan received final approval and was signed
by the City's approving officer. The Seller then registered the subdivision plan in the
Land Titles Office to create the 34 lots.
113l
ln March 2013, Mr. Kumar consulted a lawyer named Mr. Jaffer. On
March 26,2013, Mr. Jaffer sent the Seller a letter which said:
We are the solicitors for A & G lnvestments lnc. and Satish Kumar, and have
reviewed the Contract of Purchase and Sale dated April 13,2012.
It is our client's position and our considered opinion that the said Contract is
in breach of the Real Estate Development and Marketing Act, and the
Contract is void and unenforceable.
We hereby demand the return of the Deposit of $620,000.00 within 7 days
from this date.
TAKE NOTICE that unless the said amount is returned to us within the
prescribed time, we have instructions to commence a legal action against
yourselves without any further notice to you.
You are strongly urged to heed the contents of this letter and govern
yourselves according ly.
114l
On April B, Mr. Jaffer, on behalf of the Purchaser, sent the Seller a Notice of
Rescission in the following form:
A & G lnvestment lnc. v.0915630 B.C. Ltd.
Page 6
TAKE NOTICE that the undersigned, A & G lnvestment lnc. of 8193 - 149th
Street, Surrey, B.C. V3S 8N3, the Buyer under a Contract of Purchase and
Sale dated April 13th, 2012 with respect to 31 residential building lots as
described in Schedule "4" attached to the said Contract, a copy of which is
attached hereto, does hereby RESGIND the said Contract, pursuant to
Section 21 of the Real Estate Development Marketing Act; and hereby
DEMANDS an immediate release of the Deposit of $620,000.00 held by you
t15l
On April
11
, counsel for the Seller replied to Mr. Jaffer in the following terms
We are counsel for 0915630 B.C. Ltd. We have been provided with a copy of
your correspondence of April 8, 2013 and the enclosed Notice of Rescission.
It is our clients position that your clients have no basis for rescission of the
subject contract. The delivery of the Notice of Rescission is an anticipatory
breach and repudiation of the contract. Our clients accept that repudiation.
The contract is now at an end for all parties. Our clients are entitled to retain
the deposit paid and, if any additional damages are suffered, our client will
look to yours for compensation for those damages.
t16l lt is common ground that Mr. Jaffer was wrong and the provisions of the
Real Estate Development and Marketing Act, S.B.C. 2004, c. 41, did not apply to the
Contract.
Í171
The Purchaser retained new counsel who, on April 23, 2013, wrote to the
Seller's counsel and conceded that the Purchaser's claim for rescission was without
merit. ln that letter, the Purchaser took a new position. lt now alleged that the
Contract had automatically terminated on December 18, 2012 because the
Conditions Precedent had not been fulfilled by the completion date. The Purchaser
demanded an immediate return of the deposit.
t18l
By letter dated April 24, 2013, Seller's counsel opined that the letter of
April 23, 2013 evidenced the Purchaser's intention not to be bound by the Contract
and that the letter amounted to repudiation of the Contract. Seller's counsel advised
that his client accepted the repudiation of the Contract and that the Contract was
now at an end.
t19l
Shortly thereafter the Purchaser commenced these proceedings for return of
the deposit. The chambers judge rejected its claim. He found that the Contract did
not contain a true condition precedent that could have resulted in an automatic
A & G lnvestment lnc. v.0915630 B.C. Ltd.
Page 7
termination of the Contract on December 18, 2012. He found that the Purchaser did
not have a proper basis for claiming termination of the Contract on December 18,
2012. At most, it might have had a claim for damages.
l20l
The chambers judge rejected the Purchaser's submission that it had not
repudiated the Contract. He found that the Purchaser's correspondence indicated a
clear and express intention not to perform the Contract that constituted an
anticipatory breach and repudiation that the Seller was entitled to accept. ln the
result he dismissed the Purchaser's action.
ISSUES ON APPEAL
l21l
The Purchaser submits that the trialjudge committed the following errors:
A.
The trialjudge erred in law in assuming that because the clause at
issue was not a "true condition precedent", it was simply ineffective
and amounted to no more than a warranty. ln particular:
(i)
The trialjudge failed to consider that the condition precedent
suspended the obligations of the parties only until the
Completion Date and thereafter must be read to automatically
terminate the Contract if the conditions, particularly as to
existence of title and ability to convey the lots subject of the
Contract, were not met; or,
(ii)
ln the alternative, the trialjudge failed to consider whether the
failure to meet the conditions by the Completion Date,
including the existence of title capable of conveyance,
amounted to a fundamental breach of the Contract entitling the
purchaser to elect to rescind.
DISCUSSION
l22l
This appeal turns on the proper interpretation to be given to the Contract and
the consequences that flow from the fact that as of December 18,2012 fhe
Conditions Precedent had not yet been fulfilled. This Court in Kingsway General
lnsurance Co. v. Lougheed Enterprises Lfd., 2004 BCCA 421 at para. 10, set out the
governing principles of contractual interpretation:
... lt will, I hope, suffice to note that in terms of contractual interpretation, the
same principles of construction applicable to other commercial contracts
apply to insurance contracts ...; that the "court must search for an
interpretation from the whole of the contract which promotes the true intent of
the parties at the time they entered into the contract" ...; that the plain
A & G lnvestment Inc. v. 0915630 B.C. Ltd.
Page
I
meaning of the words used should be given effect unless it would bring about
an unrealistic or commercially unreasonable result ...; that evidence of the
factual background or setting of the contract known to the parties at or prior to
the date of the contract may be considered even in the absence of an
ambiguity ...; that at the same time, the words of the contract "must not be
overwhelmed by a contextual analysis" ...; and that in cases of true ambiguity
or doubt as to the meaning of the words used, the contra proferentem rule of
interpretation may be applied .... [Citations omitted.]
l23l
The parties are in agreement that the Conditions Precedent in this case are of
the kind discussed by Lambert J.A. in Wiebe v. Bobsien, 64 B.C.L.R. 295 (C A.)
at299:
But there is a third class of condition precedent. lnto that class fall the types
of conditions which are partly subjective and padly objective. An example
would be "subject to planning department approval of the attached plan of
subdivision". This looks objective, but it differs from a truly objective condition
in that someone has to solicit the approval of the planning department.
Perhaps some persuasion of the planning department will be required. Can
the purchaser prevent the condition from being fulfilled by refusing to present
the plan of subdivision to the planning department? This type of case has
been dealt with by implying a term that the purchaser will take all reasonable
steps to cause the plan to be presented to the planning department, and will,
at the proper time and in the proper way, take all reasonable steps to have
the plan approved by the planning department.
l24l
ln this case, the Conditions Precedent were objective only up to a point. The
Seller was required to take various steps that required the approval of a third party to
move the process along. There is no suggestion that the Seller acted in other than
an expedient manner in moving to fulfill the Conditions Precedent.
l25l
The Contract stated that the completion date would be the earlier of
December 18,2012 or 21 days after the Seller delivered written notice to the
Purchaser that the Conditions Precedent had been fulfilled. The Contract gave the
Seller the option to extend the completion date for up Io 270 days. The Contract
required that the Conditions Precedent be completed prior to the completion date
and went on to state "in the event that the Condition Precedent has not been met by
later of December 31,2013 (the "End Stop Date"), or such other revised Completion
Date pursuant to paragraph 5 and 6, the Contract shall come to an end, the deposit
A & G lnvestment lnc. v. 0915630 B.C. Ltd.
Page 9
shall be refunded to the [Purchaser] and neither party will have any further obligation
to the other."
126l
The Purchaser submits that the Contract automatically came to an end on
December 18,2012 when the Seller was not in a position to complete because the
Conditions Precedent at that date remained outstanding. With respect, I do not
accept that submission. Such an interpretation would bring about an unrealistic and
commercially unreasonable result. lf the proposition was sound, it would mean that
in a rising real estate market, the Seller could escape the consequences of the
agreement simply by not exercising its right to extend the completion date, leaving it
free to resell the property at a higher price to other parties. Such an interpretation
would not promote the true intent of the parties.
l27l
This case has some similarities to Peier v. Cressey Whistler Townhomes
Limited Partnership,2012 BCCA 28. That case concerned a purchase of a newly
constructed townhouse in Whistler, British Columbia. The purchase agreement
included a provision that certain power/hydro lines would be buried prior to
completion. The contract was signed in May 2007 with an estimated completion date
of December 1, 2008. lf the completion date had not occurred by December 1, 2009,
referred to as the outside date (which the vendor could for any reason extend for up
to 120 days) the purchase agreement would be terminated.
l29l
ln discussing the contract the Court described the completion date as follows
126l Under the purchase agreement, with the power lines clause, the burial
of the lines prior to completion can be said to have been essential to the
purchaser but the time of completion was clearly not. lndeed, the agreement
contained no more than an estimated completion date (December 1, 2008)
with the choice of the actual date for completion being entirely at the
discretion of the vendor. Though the agreement provided time was of the
essence, the date for completion was by no means of the essence. The only
date on which the purchaser could rely was the Outside Date (March 1,2010
as extended) on which the agreement would be terminated if the completion
date had not occurred.
l27l
What can be seen to have been important to someone in the
purchaser's position was a condition that he did not have to pay the purchase
price until the lines were buried, such that his leverage in that regard was
preserved. lf they could not be buried, or if they could be buried but were not
A & G lnvestment lnc, v. 0915630 B.C. Ltd.
Page 10
buried prior to the Outside Date, the purchase price would never have to be
paid and the deposit would be returned. There was a condition precedent that
suspended the purchaser's obligation to pay the purchase price, but the
suspension was not open-ended. The Outside Date served to give certainty
to the agreement.
l2gl
Similar reasoning applies in this case. The parties bargained for the transfer
of "ready-to-build" lots in return for moneyed consideration. The lots did not exist at
the time of contract formation. The Contract suspended full payment of the purchase
price until the lots were in a "ready-to-build" state, preserving the leverage and
interest of the Purchaser. What was important to the Purchaser was not the exact
date of completion but rather that the Conditions Precedent were satisfied prior to
the transfer so that the Purchaser would acquire "ready-to-build" lots as it intended.
The Contract was not open ended, notwithstanding the temporary suspension of the
purchase price. The End Stop Date served to give certainty to the Contract. lf the
Conditions Precedent had not been met by that date the Contract was to end.
t30]
The parties were well aware of the numerous steps that had to take place
before the Seller would be in a position to transfer "ready-to-build" lots. lndeed, the
requirement that the lots were in a "ready-to-build" state was a handwritten addition
to the Contract. The completion date set a deadline for these steps, but the date of
December 18,2012 was not essential to the bargain. What was essential was that
the steps be completed within a reasonable period of time from formation. This is
evidenced by the absolute deadline specified in the End Stop Date.
t31l
lt cannot have been the intention of the parties for the Contract to have two
automatic termination provisions, each triggered by identical circumstances, but
simultaneously operating to end the Contract on two different dates more than a
year apart. The true intention of the parlies, as revealed by the terms of the
Contract, must have been to include only one automatic termination provision for
failure to satisfy the Conditions Precedent. This automatic termination provision is
the End Stop Date of December
completion date.
31
,2013 and not the December 18, 2012
A & G lnvestment Inc. v. 0915630 B.C. Ltd.
Page 11
1321 The agreement did not automatically end on December 18, 2012. I would
dismiss the first ground of appeal.
[33]
This conclusion, however, does not answer the second ground of appeal.
I agree with
the Purchaser that the chambers judge erred by failing to consider
whether the failure to meet the conditions by the completion date amounted to a
fundamental breach of the Contract.
t34l
For the reasons that follow, I find that the error does not ultimately assist the
Purchaser or lead to a different result.
l35l
The Contract was to complete December 18, 2012. While the Seller had the
option to extend the completion date, it did not do so. Pursuant to the terms of the
Contract time was of the essence. The Seller's failure to complete on December 18,
2012 was a fundamental breach of the Contract and gave to the Purchaser the right
to accept the breach and put the Contract to an end. I do not agree with the trial
judge's analysis that the failure to complete on December 18 was a mere breach of
warranty leading to a possible remedy in damages.
t36l ln Gulsfon v. Aldred,2011 BCCA 147, this Court set out the options open to
an innocent party when there was a breach of a fundamental term:
t50] Where there is a breach of a fundamental term, the innocent pañy has
two options. As this Court stated in Morrison-Knudsen Co. lnc. v. British
Columbia Hydro and Power Authority, (1978) 85 D.L.R. (3d) 186 at para. 130:
... However, it is not every breach which determines a contract and
puts an end to contractual obligations. There are breaches
compensable in damages only and breaches called fundamental
breaches which can bring the contractual relationship to an end and
free the parties from fudher performance. When faced with a
fundamental breach the innocent party is put to an election. He may
elect to affirm the contract and to hold the other party to the
performance of his obligations and sue for damages as compensation
for the breach. He may, on the other hand, elect to treat the breach as
a fundamental breach and accept it as such. Thus he would terminate
the contract and thereafter be relieved of any further duty to perform
and he could sue at once for damages or quantum meruitlor
pedormance to that point. lt is essential that such election. an election
between inconsistent riqhts. be made promptlv and communicated to
A & G lnvestment lnc. v.0915630 B.C. Ltd.
Page 12
the ouiltv partv. Once made. the election is bindino and cannot be
chanqed. [Emphasis added.]
t37l
On December 18, 2012, when the Contract did not complete, the Purchaser
had an election. lt could affirm the Contract and hold the Seller to the performance of
its obligation or it could elect to treat the breach as a fundamental breach and accept
it as such. lf it elects to terminate the Contract, then it would be entitled to return of
the deposit.
t38]
An election between inconsistent rights must, however, be made promptly
and communicated to the other side. Parties cannot adopt a "wait-and-see"
approach to fundamental breach, as their election simultaneously determines the
position of the counterparty to the contract. Either the contract is not repudiated and
the rights and obligations under it still exist, or the contract is rescinded because of
an accepted repudiation and then very different rights come into being in respect of
a cause of action. ln either case, parties must have prompt notice of their position. ln
this case, the Purchaser did nothing on December 18, 2012 to indicate it had made
an election. Indeed, through to March 2013, it continued its attempt to resell the lots
while the Seller continued the work necessary to fulfill the Conditions Precedent.
t39l
The Purchaser did not suggest the Contract was at an end until its counsel's
letter of March 26,2013, and then for reasons unrelated to the failure to complete
the Contract on December 18,2012. lt was not until April 23, 2013 that the
Purchaser first alleged that the Contract had come to an end because the Conditions
Precedent had not been fulfilled by the completion date.
t40l April 23, 2013 was much too late to put the Contract to an end for a failure to
complete on December 18, 2012. An election must be made promptly. ln this case
it was not. By April 23, 2013 the Purchaser could no longer rely on the Seller's
December 18,2012 breach as a fundamental breach of contract.
l41l
ln its letter of April 23,2013, the Purchaser indicated it would not complete
the Contract. The Seller had the right to accept that letter as an anticipatory breach
A & G Investment lnc. v. 0915630 B.C. Ltd.
Page 13
of contract and declare the Contract at an end. ln these circumstances the
Purchaser is not entitled to the return of its deposit.
l42l
lwould dismiss the appeal
"The Honourable Mr. Justice Goepel"
I
AGREE
"The Honourable Mr. Justice Donald"
I
AGREE
"The Honourable Madam Justice Bennett"