theoretical risk identification within the nigeria east- west

Transcription

theoretical risk identification within the nigeria east- west
Civil Engineering and Urban Planning:An International Journal(CiVEJ) Vol.2,No.1, March 2015
THEORETICAL RISK IDENTIFICATION WITHIN
THE NIGERIA EAST- WEST COASTAL
HIGHWAY PROJECT
Samuel Ekung*1, Lashinde Adeniran2& Emmanuel Adu2
*1
Department of Quantity Surveying, Imo State University, Owerri, Nigeria
2
Department of Quantity Surveying, University of Uyo, Uyo, Nigeria
ABSTRACT
This study examined principal risks affecting performance in the Nigeria’s east-west coastal highway
project. The objective was to identify critical risks and their allocation preference. The study involved a
two tier descriptive research processes. The first stage involved 10 high profile engineering design
consultants and 6 projects managers, and the second stage was a survey of 66 construction/projects
managers in Akwa Ibom and Rivers states, Nigeria. During the first stage, respondents were presented
with a risk register containing 245 risk factors relating to the pre-construction stages to determine their
applicability in the project. In the second phase, critical risks were ranked for degree of impact and
likelihood of occurrence. Risk matrix was used to map risk impact and probability. Among the high
impact/probability risk factors are government lack of political will; change in government, and
corruption. 66% of the risks are allocated to contractor while the client bears only 34%. To ensure smooth
delivery of the project, the study advocates the allocation of all policy; economic, financial, social,
environmental, and technological risks to the client based on their shifting nature and existing contractual
practice. The study provides an in-depth risk analysis and a comprehensive risk register for managing
risks apparent in the project.
KEYWORDS
Coastal engineering, large construction project, Nigeria’s coastal highway, risk, and risk management
1.INTRODUCTION
Coastal engineering projects involve a broad range of forms which are influenced by the action of
water, tide and currents, wave actions and highest level of risks [17]. Construction in marine
environment imposes diverse risk, the hazard involved, the antecedent cost, and environment
consequences originate from three main perspectives. First, is the variability and uncertainties of
storm, wave, swell, current and tidal and surge events;second, the need to work over, and supply
material via water rather than land, and finally, the lack of adaptation of land-based clients,
contractors, designers and insurers, procedures and contracts to these special circumstances.
Improper consideration of the risk in coastal engineering like every other project endeavour could
deter performance objectives’ realisation.
The Nigeria East-West Coastal road project is unique and the very first in the region. The
Nigerian coastal highway span 731Km with over 206Km straddling over barrier Island forest,
fresh water swamps, mangrove swamps and inland water ways. Engineering design of the project
shows an alignment that crosses almost 60 water bodies requiring 180 bridges. The world fifth
longest cable stay bridge is to be constructed in this project. These unique features have placed
1
Civil Engineering and Urban Planning:An International Journal(CiVEJ) Vol.2,No.1, March 2015
significant impetus on the need to study the risk attributes of the project in order to improve the
delivery process. Road transportation accounts for over 90% of the movement of people in
Nigeria [12] including goods and services. The traveling distance between two ends Calabar and
Lagos in the project takes 10 to 12 hours via road; and on completion, this travelling time will be
half. The road is also intended to facilitate regional integration and linkage of coastal economies
to the national economy in Nigeria.
Over the years, risk management has become the main stay of critical infrastructure projects
decision making process. The objective behind risk management has shifted from enhancing an
understanding of all stakeholders, to also facilitating possible agreement on what the threats to
the project objectives really are and how they will be managed [2]. To generate appropriate value
in today’s unstable environment, analysis of possible risk has become the cultural ethics towards
delivering success. Risk assessmentis also critical for establishing an efficient cost estimating
improvement system that can be used to benchmark areas of potential problems thereby
checkmating cost overrun [9]. It enhances continuous improvement in decision making and
increases the probability of completing the project on time, budget and on other performance
objectives. Based on the need to improve performance and ensure successful delivery of the
proposed project, this study is conducted to provide useful empirical insight into imminent
threats to performance realisation. The objective is to carry-out an assessment of imminent risks
in the project, proffer mitigation strategies and assess the allocation preference within the context
of the Nigerian construction industry’s practice.
2.Theories of Risk Management in Coastal Engineering
Conventionally, risk management has been used instinctively while risks yet remain ‘implicit’
and controlled by judgement based on experiential knowledge [18].[17] argue that risk
management should make risk explicit, formally describing and making them it easy to manage.
Traditional risks assessment is based on expert opinion of perceived risks factors and this is
widely used [6]. The utility theory is another widely adopted technique based on the ability to
generate both qualitative and quantitative data (e.g. [5]). In this approach, respondents mainly
professionals in the construction industry are required to assess the probability of occurrence and
the degree of impact of a particular risk factor using numerical scales. Other tools AHP
(analytical hierarchical process) and fussy theory [10] are also widely used.
The methodology for evaluating coastal engineering construction risks has undergone
fundamental improvement, navigating from conventional ‘deterministic’ approaches to
probabilistic techniques[8]. The improvement has impacted significantlyon the planning and the
engineering processes of project development. The modification in risk analysis approaches is
necessitated by a number of factors. First, the understanding of the probabilistic coastal processes
has improved due to advances in field quantification, physical and numerical modelling
[7].Second, standards of computing capabilities are growing significantly thereby promoting
lengthened probabilistic calculations which were impracticable in the past.Third, the drives to
implement better approaches that clearly illustrate improved analysis by practitioners have also
emerged.
Two approaches are prominently used in coastal engineering construction risk assessment (16; 7],
the frequency theory or frequency based approach and the life cycle approach. The frequencybased approach deals with the frequency of occurrence and its relationship with other key
2
Civil Engineering and Urban Planning:An International Journal(CiVEJ) Vol.2,No.1, March 2015
variables. The frequency approach combines forcing parameters with numerous occurrence
frequencies to develop frequency of occurrence of key project response. The life cycle approach
on the other hand,considers several possible development of the project with time during its life
cycle. The life cycle approach is most suited to most coastal engineering projects [22]. This is
because variation is essential in most coastal projects and it is directly co-opted into life cycle
method. Other considerations such as functional performance variation, construction variation
season and other economic and social environmental factorsare equally incorporated in the life
cycle approach (ob. cit). The approach therefore leads to a unified analysis of technical
performance and numerous economic factors that are determinants of project success.
Consequently, it is widely acknowledged to be easily understood by non- technical stakeholders.
However, [18] suggested the use of generic risk management methods on coastal engineering
projects. This method, according to these authors, ensures proper identification and allocation of
risks to the party best able to manage them. Their assessment strictly canvasses the use of
software which however may not be available to project managers and other stakeholders in
developing countries.Consequent upon the established impediments, the study utilises life cycle
risk management approach in assessing the perceived risks in the Nigeria’s east- west coastal
project.
2.1 Literature on Risk Management in Large Construction Projects
Studies in risk management in the Nigerian construction industry focused mainly on contractor’s
risk management practices and performance [20]. Very few have studied risks in large
construction projects (1;4). [23] studied risk in offshore engineering projects but failed to identify
specific risks affecting off-shore projects. [18] studied risks in coastal engineering projects but
focused mainly on river averment and shoreline protection works. [12] developed tools for flood
risk and strategies for adaptation to climate change as an integral part of risk management in
coastal engineering. From extant literatures, it becomes apparent that there is research dearth
which attempts a life cycle understanding of imminent risk in coastal engineering projects.
According to [17],existing literature tend to consider ‘small details’ which concentrate on the
environment alone. There is need therefore for an empirical study with a ‘global
discussion’perspective to identify principal risk in coastal engineering projects in all aspect of
social, legal, political, environmental, economic and technological fronts.
With emphasis on the pre-construction stage, the present study attempts a holistic analysis of risk
factors in coastal engineering in the Nigeria’s east-west coastal highway project. The need for the
study stems from the strategic important, this project portrays to the Nigeria’s economic
development. More so, given the shifting social, political and economic variables in developing
countries amidst significant infrastructure gap to be filled [19]; the study will contribute
significantly to project management knowledge in emphasising the need to address front-end
issues as determinants of project success [15]. The objective is to determine perceived risk
factors in the pre-construction stages of the project and to determine risk allocation preference
practices among construction stakeholders in Nigeria. An understanding of stakeholders’ risk
perception is essential to developing strategies for risk assessment and management. The
effectiveness of risk assessment approach also depends on the diversity of stakeholders’
perception as it will engender opportunities for collaboration [15].
3
Civil Engineering and Urban Planning:An International Journal(CiVEJ) Vol.2,No.1, March 2015
3. Research Methodology
To achieve the objectives of the study, a three tier research design was adopted. First, an in-depth
literature search was carried-out to identify risk factors associated with coastal engineering
projects. The aim of the literature search was to generate a comprehensive list of imminent risk
factors associated with the project and to produce a ‘prime version’ of the risk register. The risk
factors generated individually and collectively from practice and literature formed the basis for
the second phase of the research.During the Second phase, the risk register containing 245 risk
factors was presented to relevant stakeholders in engineering project delivery to identify critical
risks that may affect the Nigerian east-west coastal highway project. To enhance quantitative risk
assessment, respondents were asked to identify the likelihood of occurrence and degree of
impact. The sample in this phase was determine using convenient sampling with 16 respondents
comprising ten high profile engineering consultants and six project managers. Third, the critical
risk factors which formed the risk matrix were presented as a survey questionnaire to a purposive
sample of 66 project and construction managers selected from 32 construction organisations in
Akwa Ibom and Rivers States, Nigeria. Purposive sampling was adopted due to the inability to
aggregate and stratify firms into categories with capability to successfully undertake the scope of
project envisaged in the study. The targeted population were project and construction managers
in large and medium sized firm categories which are both national and international contractors
with tendency to internalised and tap expertise abroad in executing similar projects. Selfadministration was used to administer and retrieval was also done personally. The method was
largely successful due to extreme personal contact involved hence, the significant response rate
of 35.5% recorded. The respondents were required to identify and rank the likelihood of
occurrence and degree of impact of 44 risk factors validated from stage two using a 3-point
Likert scale and their allocation preference, and to also suggest mitigation strategies. Allocation
preference was to identify who in the opinion of the respondents can conveniently or will likely
bear each risk in order to ascertain the risk preference. Mean item score was used to determine
the hierarchy of each risk factor. Risk factors with degree of impact and likelihood (3) are
designated ‘H’, high; 2, ‘M’, medium; and 1, L, low.
4. Results
A total of 145 risk factors were assessed in 17 categories. Risks in the register and matrix below
are identified as: political P1-7; Financial F1-11; Technical- Project Accommodation Tp1- 6;
Technical Demolition TDe1-TDe10; Technical Early Works TE1- TE6; Technical Ground
Condition TGc1- 5; and Technical Design TD1- 25. Others are: Economic E1-3; Technological
TL1; Technical Logistics T1-2; Technical Archaeological TA1-3; Legal L1-3; Environmental
Ev1-16; Social S1 -10; Project Management PM1-5; Cost Management CM1-5; and construction
Risks C1-27.
Risk in Box 3 (Risk Matrix- Figure 1) cannot be tolerated if the project must succeed. The risk in
this category includes policy risks; finance, design risk, environmental and social risks. The risks
in box 5- yellow colour can be tolerated if it is economically and technically unreasonable to
reduce them. The green region contains acceptable risks. The implication is that the presence of
these risks in the project cannot deter the attainment of key project objectives.
4
Civil Engineering and Urban Planning:An International Journal(CiVEJ) Vol.2,No.1, March 2015
4.1 High Impact High Probability Risks
These risks are those whose likelihood (probability) of occurrence is between 70 to 100%. They
are P1, P2, P5, F1, F8, TP2, TP3, TP4, TP5, TD1, TD3, TD11, TD12, E1, E2, E7, E8,E14, S4,
CM1, CM4, C3, C6, C10, C12, C21, and C27.
P1 (Government lack of Political will):- The project was first identified in 1991 as part of the
UNDP/Federal Government of Nigeria Action to develop the oil rich Niger Delta among others.
20years after, the project design was concluded in 2012. Successive governments (2 military
administration and 3 past civilian rules) did not prioritised the project. Following this trend
therefore, tendency of non-implementing this project is significantly high. More so, committing
such a huge budget to fund a single project in a region in five years is not feasible based on
political grounds.
P2 (Change in government):- Nigeria is ruled on ethnic divides with very little nationalistic
objectives. Successive governments had been the majority; the project is prioritised now because,
a minority from the region is in power. The polity is tensed because the major wants back power.
The incumbent’s tenure ends in 2015 and the implication is that, the project might be abandon.
This is why the study recommends legislative backing for the project.
F8 (Corruption and Financial Fraud):- Following 23years of military rules, the macro
environment is characterised by corruption, wealth amassment and embezzlement. The tendency
that, the project will be budgeted for,and fund diverted is very high due to weak institutional
frameworks. The consequence is delayed payment to contractors, delay and cost increases. Delay
and cost increases in federal government projects in Nigeria are very high.
Figure 1: Risk Matrix
TD1 (Insufficient Design Details):- Due to the use of traditional procurement system which
does not allow early involvement of the contractor, the tendency of insufficient production details
is high. Several studies in this regard have proven the approach susceptible to related problems.
The implication at the production stage might result in redundant time to get details and the
adequacy of such details can also be questioned. Programmed delay is inevitable and this can be
significant based on the scope of the project.
5
Civil Engineering and Urban Planning:An International Journal(CiVEJ) Vol.2,No.1, March 2015
TD3 (Incompetent Design Team):- The design organisations are mainly indigenous consultants
in partnership with foreign firms, the certainty of their collaborations my not be reliable or
realistic. Like earlier mention, the skill requirement in the construction sector is inadequate like
every other developing country. The greatest challenge is in the cable stay bridge. The tendency
of engaging firms not on merit and competency is also very high. The chances of very high
incompetent design team producing faulty design solution are 50:50.
TD11 (Ground Condition):- Over 80% of the total landmass of the Niger Delta region is either
swamp, marshy or river. Site investigation cannot be conducted on the whole stretch of the
project; the tendency of encountering an unsuitable ground condition is high. The chances of
encountering unstable ground arealso very high. The consequence could mean complete inability
to implement project at some point including associated delays, redesign cost and rework costs.
E1 (Market Condition):- The macro economic variables in Nigeria are very unstable and
unpredictable. The inflation and exchange rates are equally very unstable and since true cost is in
the market place (obtained in tenders), the chances of significant variation from what is budgeted
for is very high. Where this occurs, the implication is that, the project cannot be awarded against
budget and this may necessitate suspendingthe project.
EV1 (Flood/Coastal Surge Risks):- Flood risk disaster is on the increase in Nigeria, the
shorelines are largely unprotected and the possible insurgence of flood risks from heavy down
pour, sea and beaches fluctuation are significantly very high. The outbreak can significantly
disrupt construction leading to redesigning, delay, rework and their associated costs.
EV2 (Exceptional Inclement Weather):- The true raining season in the thick rainforest region
of the Niger Delta is nine against 7 months largely predicated from experts. This again depends
heavily on sea wave from the nearby coast. This is a very significant threat to the timely delivery
of the project. Extension in time is inevitable.
S4 (Militant Insurgence):- Arm taking and militancy is a black swan event in the area. In the
past so many multinational coy have abandoned many on-going contract due to hostage taking,
killing and disruption of work. The causes are often wide ranging; it could be a revenge or protest
against government policy in other areas, excessive demands than the contractor can meet or
other criminal tendencies. At the moment, there is a warning of possible attack on government
and multinationals and locals as a result of Boko Haram insurgency up north.
4.2 Medium Impact Medium Probability
These risks are those whose likelihood (probability) of occurrence is between 50 to 70%. They
are TP6, TD13, TD18, E9, E10, C1, C14 and C16.
TD7 (Inaccurate Survey Data):- Survey data are significant design and construction
requirement in every infrastructure. The tendency of survey data being marred with flaws is very
high. Incompetency is the leading responsible factor while long stretch and difficulty of
generating these data are equally very high. Deep sea diving and the use of advance technology is
involve but the first is a high risk endeavour while the latter is associated with high cost. As a
result, concern parties might want to use intuitions which may not be accurate positively. Faulty
data means ineffective design and project performance objective is not being met.
6
Civil Engineering and Urban Planning:An International Journal(CiVEJ) Vol.2,No.1, March 2015
TD13 (Condition of Existing Structures):- Most section of this project are not entirely virgin,
therefore the tendency of incorporating existing structure such as bridges is high. These bridges
were built some 60years ago and require replacement. The risks of retaining these structures for
cost saving or due to faulty condition analysis is feasible.
4.3 Low Impact Low Probability
These risks are those whose likelihood (probability) of occurrence is between 50 to 70%. They
are P3, P6, P7, TDe7, TDe8, TDe9, TDe10, TE6, TD5, TD6, TD9, TD12, TD21, T1, TA1, TA2,
TA3, TA4, and S6.
P3 (Inadequate Government Consultation):- Roads project construction in Nigeria is governed
by fiscal federalism. This is a federal road project coordinated by the central government with
different jurisdiction and authority. Therefore consultation with states and local government is
irrelevant. The existing institutional framework is not strengthened to allocate appropriate
commensurate rights to states and local government on this matter.
TP2 - Failure to Vacate Property Accommodation by Occupants):- Once properties are paid
for and sufficient time is given in notice, such occupiers are expected to vacate although some
might be adamant. The risk is in this category because where proper settlement is done
compulsory demolition is imminent.
TDe8 - Additional Security to Demolished Properties):- Inability and unwillingness of owners
to protect their properties during construction can result in litigation. However, owners of
demolished properties are to provide relevant security to their properties after demolition e.g.
fence.
TDe10 - Insufficient Working Space for Demolition: - Demolition harbours significant safety
hazards. The probability of this risk is very low because the region is largely undeveloped with
traditional settlements made in crude materials.
TD9 - Multiple Approval Problem: - It was earlier mentioned that roads are govern by
jurisdiction vested on the three tiers of government. The project is coordinated at the centre
hence; there is very little need to seek approval from state and local government. State and local
government are mere beneficiaries.
5. Discussion
One critical attribute about the study respondents’ perception of the risk factors is the
homogeneity with which all respondents agree and rank every risk factor. Risk perception in the
construction industry is widely agreed to be heterogeneous; with individual risks having different
likelihood of occurrence and consequences [15]. Policy risks received very little mention in
research literature notable where public sector finance projects are examined. Although, thereare
numerous literaturesexamining joint venture projects in the construction sector. Policy risks are
known as political risks in the general domain. They are unexpected variation in value as a result
of unexpected discrepancy in public authority’s action [14]. Many high impact and high
probability risks in this study are consistent with study by[4]. [4] studied risk factors impacting
highway construction in Nigeria; and identified contaminated soil, design changes and inaccurate
design details. [14]also analysed policy risk as the key constraint to business investment
globally.
7
Civil Engineering and Urban Planning:An International Journal(CiVEJ) Vol.2,No.1, March 2015
Table 1: Principal Risk Factors in Nigeria’s East-West Coastal Highway
Ref
Category
Heading
P1
Political
Government
lack
Political will
Change in government
Political indecision
Low budgeting
Mitigation Strategies
IM
PF
H
CL
H
H
H
H
H
H
CL
CL
CL
H
H
H
H
CL
CL
H
H
CL
H
H
H
H
CL
CL
Incompetent design team
Ground condition
Government to show adequate commitment to
project
Backed project with legislation
Adhere to implementation milestone
Prioritized funding & seek joint funding other tiers
of government
Engage reputable private fund manager
Prioritize key acquisition to enable expedient
demolition
Design consultants to submit full and detailed as
applicable
Engage best in class consultant
Site investigation should be thorough
Design error
Peer review design
H
H
CL
Economic
Market condition
H
H
CL
Environmental
Flood/coastal surge
Surface run-off
Exceptionally
adverse
weather
Coastal erosion
Beaches fluctuations
Improve estimate to allow for varying market
condition
Design for sea revetment and sea wall as appropriate
Provide mitigation measures
Program to fit float where possible
H
H
H
H
H
H
CL
CL
CL
EIA should address this problem
Adopt wait-and-see method with contingency for
mitigation
Prioritize and
engage extensively before
construction
Monitor and provide for security
Benchmark base estimates
H
H
H
H
CL
CL
H
H
CL
H
H
H
H
CL
CL
Uncertainty of project
budget
Poor labourers training
Investigate and current tools for cost estimates
H
H
CL
Provide adequate training for employees
H
H
CR
C5
C6
C10
C12
Lack of professionals
Force majeure
Political instability
Construction tolerance
H
H
H
H
H
H
H
H
CR
CL
CR
CL
C21
C27
TP6
Accessibility
Dredging & disposal
Difficulty
in
serving
vesting notices
Miscellaneous delay issues
Contractor to explore local content
Appropriate remedies in contract
Study closely to understand political climate
Design consultant to recognize what is achievable
rather than what is desirous
Extensive pre-construction surveys
EIA should identify mitigation measure
Undertake advance consultation
H
H
M
H
H
M
CLR
CLR
CL
Improve identification of miscellaneous causes
M
M
CR
Engage competent consultant and
equipment
Preliminary survey should be thorough
M
M
CL
M
M
CL
Detour traffic as much as possible
M
M
CR
Fund should be release in advance of construction
M
M
CL
Ensure all tiers of government are well consulted
L
L
CL
L
L L
L
CL
CL
L
L
CL
L
L
CL
P2
P5
F1
F8
Tp1
TD1
TD3
TD1
0
TD2
2
E1
Ev1
Ev2
Ev7
Financial
TechnicalProject
Technicaldesign
Ev8
Ev14
S3
S4
CM1
Social
Cost
Management
CM4
C3
TE4
TD7
TD1
3
TD1
8
C1
P3
P6
TP6
TDe
8
TDe
Construction
Risk
Technical
Project
Technical
Early works
Technical
Design
of
P
R
H
Corruption & fraud
Funding
shortfall
to
acquire right-of-way
Insufficient design details
Stakeholder management
Militant insurgence
Inaccurate cost plan
Inaccurate design data
Existing structures
Construction
Risk
political
Technical
Project
Technical
demolition
Dilapidation to existing
infrastructures
Delay in supply of offshore
components
Inadequate
government
consultation
Political opposition
Failure to vacate right of
way
Additional security for
demolition
Difficulty in demolition
modern
Seek opposition support based on economic benefit
Pre-construction planning should be done in
advance
Property owners should be mandated to vacate after
payment
Review schedule of property to be demolish
8
Civil Engineering and Urban Planning:An International Journal(CiVEJ) Vol.2,No.1, March 2015
9
TDe
10
TD5
TD9
Td11
T1
S6
Technical
Design
Technological
Social
Insufficient working space
for demolition
Changes
in
design
standards
Multiple approval problem
Unexpected utility crossing
Technology obsolesce
Public objection
Contractor to consider careful phased approach
L
L
CR
Prioritization of the project is work as planned
L
L
CL
Approval body should be harmonized
Site investigation should be thorough
Prioritized the project as planned
Ensure sufficient engagement
L
L
L
L
L
L
L
L
CL
CL
CL
CL
H = high; M= medium; L =low; CL =client; CR = contractor; CLR = client/contractor, PR =probability,
IM = impact; and PF = preference
Although Irvin’s assertion is in respect to privately financed projects, the shifting political,
economic and social variables pattern in Nigeria significantly substantiate his position. [4]; [22];
and [23] also identified political risks and market condition among the critical risks factors in
offshore projects. [15] identified land acquisition issues as a factor in road construction in India.
66% of the identified risks are transferrable to the contractor (Table 1). The proportion of risk
retained by the client is 34%. Respondents from public client organisations disagree significantly
on the governance of risk considered client’s risks. They believe the contractor is paid premium
to take up the responsibilities. But the underlying denominator, which needs an insight, is the
trend in risk avoidance by the public sector client. The guiding principle governing risk allocation
in the management of risk remains, the party which is best able to manage risk are allocated
significant risks. In the present study, the chunk of the risks are better retained and managed by
the client or jointly managed with the contractor for optimal result. [14] argues that policy risk
for instance should be allocated to the public sector client.Allocation of risk should be tailored in
accordance with an understanding of the project objectives. These must be clearly communicated
to all parties at the inception of the project.Risk allocation principle shown in this study is
therefore ‘a one-size-fit all processes designed to ridicule project objectives [17].
While there is need to promote risk sharing in line with the emerging trend globally; to
implement this project based on the existing contractual form, all policy, economic, financial,
technical, social, environmental, technological risk should be retained by the client. Contractors
are better disposed to manage construction risks.
6. Conclusion
Coastal engineering projects present unique characteristics different from conventional
construction projects. This study, using the Nigeria’s east-west coastal highway project
determined the critical risk factors in coastal engineering projects and their allocation preference.
The study focused on the pre-construction stages of the project based on the increasing emphasis
on the need to pay attention to front end issues as determinants of project success.A risk register
containing 245 risks factor was presented to relevant stakeholders- design consultants and project
managers selected from consultant and contractor’s organisations to identify perceived risks
which may influence project performance. 44 risk factors were validated significant. 27 are high
impact/probability factors; 6 are medium impact/probability factors while 11 are low
impact/probability factors. Among the high impact-high probability factors are: government lack
of political will; change in government; political indecision; low budget; and corruption. 66% of
the risks were allocated to the contractor while 34% are retained by the public sector client. The
study suggests risk allocation should be tailored according to an understanding of the project
9
Civil Engineering and Urban Planning:An International Journal(CiVEJ) Vol.2,No.1, March 2015
objectives, which must be clearly communicated to all parties at the inception of the project. To
improve the delivery of the project, all policy, economic, financial, technical, environmental, and
technological risks should be retained and managed by the client. The contractor should be
allowed to focus on the management of construction risks. The study provides an in-depth risk
assessment and analysis towards the management of risk in Nigeria’s east-west costal highway
project.
This study implements mainly survey research design which adopts and tested risks from the
literature. The tendency subsists that the designed survey instrument may not enlist all salient
risks that can affect project performance. A mixed approach study is therefore recommended
notably semi-structured interviewing with a selected group from the survey’s sample to be able to
tap from their repository of experiential knowledge to enrich the risks tested in this study.
References
[1]
[2]
[3]
[4]
[5]
[6]
[7]
[8]
[9]
[10]
[11]
[12]
[13]
[14]
Adedokun, O.A.; Ogunsemi, D.R.; Aje, I.O.; & Dairo, D.O. (2012). Evaluation of Risk Analysis
Techniques in Selected Large Construction Companies in Nigeria, Emerald Group Publishing,Preprinted version.
Adnan, H. (2008). An Assessment of Risk Management in Joint Ventures (JV) Projects in Malaysia,
Asian Social ScienceJournal, 4(6): 99 -106
Anderson, S.; Molenaar, K.R. &Schexnayder, C. J. (2008). Guidance for Cost Estimation and
Management for Highway Projects During Planning, Programming, and Preconstruction,
Transportation Research Board of the National Academies
Awotunde, G.B. (2010). An Evaluation of Risk Impacting on Highway and Road Construction in
Nigeria, 8th International Conference on construction & Real Estate Brisbane, Australia 1-3
December, 336-344 available @ http://arrow.unisa.edu.au:8081/1959.8/119503 accessed 22/7/2013
Chan, D.W.M., Chan, A.P.C., Lam, P.T.I., Yeung, J.F.Y., Chan, J.H.L., (2011). Risk Ranking and
Analysis in Target Cost Contracts: Empirical Evidence from the Construction Industry,International
Journal of Project Management 29(6): 751–763.
Choi, J.; Chung, J., Lee, D.J., (2010). Risk Perception Analysis: Participation in
China's
Water
PPP Market, International Journal of Project Management, 28 (6):
580–592.
Clausner, J. E., Melby, J.A., Scheffner, N.W.,Butler, H.L. (2008). Coastal Engineering – Planning
and design Process, Huston: PDHEngineer.com Continuing Education for Engineers.
COWI (2012). Marine and Coastal Engineering,
Ocean & Coastal Consultants, Inc.,North
America, available online ww.cowi.com/menu/project…accessed 2/6/13
Creedy, G. D.; Skitmore, M. & Wong, J. (2010). Evaluation of Risk Factors Leading to Cost Overrun
in Delivery of Highway Construction Projects, Journal ofConstruction Engineering and Management,
136(5):528-536
Dikmen, I., Birgonul, M.T., Han, S., (2007). Using Fuzzy Risk Assessment to Rate Cost Overrun
Risk in International Construction Projects, International Journal of Project Management,25(5):494–
505.
Garland, R. (2009).Project Governance: a Practical Guide to Effective Project Decision Making,
London and Philadelphia, Kogan Page Limited
Grimm, C.; Woffler, T.; Bacmann, D. &Schuttrumpf, H. (2012). Risk Management in Coastal
Engineering, Applied Coastal Research Projects for Northern Germany, Water and Waste, 53 -55
Ighodaro, C.A. (2009). Journal of Research in National Development, Journal of Research in
National Development, 7(2): 22 -34
Irwin,T.C. (2008) Government Guarantees, Allocating and Valuing Risk in privately
Financed Infrastructure Projects. The World Bank
10
Civil Engineering and Urban Planning:An International Journal(CiVEJ) Vol.2,No.1, March 2015
[15] Lu,S. & Yan, H. (2013). A Comparative Study of the Measurement of Perceived Risk among
Contractor in China, International Journal of Project management, 31:307– 312
[16] Maharaj, R.J (2000). Lectures on Coastal
Hydrodynamics, Processes & Risk in Coastal
Engineering
and Management, University of the South Pacific, FIJI
[17] Simm,J. & Cruickshank, I. (1998). Construction
Risk
in
Coastal
Engineering,
London:Thomas Telford, 155-178
[18] Simm,J.D.&Camelleri, A.J. (2001).Construction Risk in Coastal and River Engineering,J.CIWEM,
15: 258 -264
[19] Tolani,O.V. (2013). An Examination of Risk Allocation Preferences in Public-Private Partnership in
Nigeria, Afe Babalola Journal of Sustainable Development Law and Policy, 2(1) 206-221
[20] Windapo, A. & Martins, O. (2010). An Investigation into Nigerian Property Construction Companies
Perception of Critical Risk, Insurance Markets: Analysis and Actuarial Computations, 1(1):78- 83
[21] Zou,P and Zhang, G (2009). Managing Risks in Construction Projects: Life Cycle and Stakeholder
Perspectives, International Journal of Construction Management, 9(1):61-77.
[22] Zou,P.;Zhang, G.;& Wang,J.(2011).Identifying Key Risks in Construction Projects: Life Cycle and
Stakeholder
Perspectives,
available
online
at
http://www.prres.net/papers/Zou_risks_in_construction_projects.pdf accessed 18/7/13
[23] Zuofa,T.& Ochieng,E.G.(2011).Project Managers Perception of Risk Factors in Heavy Engineering
Construction Projects: case of Offshore Projects In Egbu, C. & Lou,E.C.W.(eds) Procs of 27thAnnual
ARCOM Conference, 5-7 September 2011, Bristol, UK, Association of Rsearchers in Construction
Management,985-993.
11

Similar documents

LETTER TO THE CHIEF OF ARMY STAFF NIGERIAN ARMY REQUESTING OFFICIALLY FOR THE SERVICES OF TWO MILITARY PERSONNEL IN OSUN STATE, NIGERIA By Professor (Grandmaster) Adefioye Sunday Adewumi

LETTER TO THE CHIEF OF ARMY STAFF NIGERIAN ARMY REQUESTING OFFICIALLY FOR THE SERVICES OF TWO MILITARY PERSONNEL IN OSUN STATE, NIGERIA By Professor (Grandmaster) Adefioye Sunday Adewumi This letter was sent to the Chief of Army Staff of the Nigerian Army on 25th of January, 2017 to officially request for the services of two undercover military personnel in Ile Ife, Osun State, “Nigeria”. The Chief of Army Staff have the apex and highest authority over ALL Military affairs that involve ALL Nigerians within the Nigerian border including making independent military decisions and embarking on independent intelligent military operations inside "Nigeria". The letter is presented exactly as it was sent via the Nigerian Army website to the Nigerian Military Number One Person and Chief raw and unedited.

More information