Athletic Facilities - Borbon Inc painting

Transcription

DESERT COMMUNITY COLLEGE DISTRICT
AGREEMENT
THIS AGREEMENT is made this 3rd day of January, 2013, in the City of Palm Desert, County
of Riverside, State of California, by and between DESERT COMMUNITY COLLEGE DISTRICT, a
California Community College District hereinafter "District" and BORBON INCORPORATED .;
("Contractor").
WITNESSETH, that the District and the Contractor in consideration of.the mutual covenants
contained herein agree as follows:
1. The Work. Within the Contract Time and for the Contract Price, subject to adjustments thereto
pursuant to the Contract Documents, the Contractor shall perform and provide all necessary labor,
materials, tools, equipment, utilities, services and transportation to complete in a workmanlike
manner all of the Work required in connection with the work of improvement commonly referred to
as ATHLETIC FACILITIES; Bid Package No. 011200.24; Bid Package Description: Painting. -/
Contractor shall complete all Work covered by the Contract Documents including, without
limitation, the Drawings and Specifications prepared by the Architect, LPA, Inc., and other
Contract Documents enumerated below, along with all modifications and addenda thereto issued
in accordance with the Contract Documents.
2. Contract Time. The Work shall be commenced on the date stated in the District's Notice to
Proceed; the Contractor shall achieve Substantial Completion of the Work within the Contract
Time set forth in the Special Conditions.
3. Contract Price. The District shall pay the Contractor as full consideration for the Contractor's full,
complete and faithful performance of the Contractor's obligations under the Contract Documents,
subject to adjustments of the Contract Price in accordance with the Contract Documents, the
Contract Price of One hundred sixty-nine thousand sixty-nine Dollars ($169,069.00).
I
The Contract Price is based upon the Contractor's Base Bid Proposal and the following Alternate
Bid Items: NONE.
,/
The District's payment of the Contract Price shall be in accordance with the Contract Documents.
/
Unit Prices, if any, are as follows: NONE
The Contract Price will be increased by an amount equal to the unit price multiplied by the actual
number of units of each unit price item incorporated in the Work.
4. Liquidated Damages. Should the Contractor neglect, fail or refuse to: (i) timely submit
Submittals in accordance with the Baseline Construction Schedule or the Updated Construction
Schedule, as applicable; (ii) achieve Substantial Completion of the Work within the Contract Time,
(subject to adjustments authorized under the Contract Documents); or (iii) complete Punchlist
items within the time established pursuant to the Contract Documents, the Contractor agrees to
pay to the District the per diem Liquidated Damages set forth in the Special Conditions, not as a
penalty but as Liquidated Damages, for every day beyond the Contract Time, as adjusted, until
Submittals are submitted, Substantial Completion is achieved or the Punchlist items are
completed. The Liquidated Damages set forth in the Special Conditions are agreed upon by and
BORBONINCORPORATED
01·03·13
$169,069.00
AGREEMENTDATEO:
ATHLETIC FACILITIES
41-251-0283-0-0835-0000-6210
EIS PROJECT #230043
AGREEMENT
PAGE 1
between the Contractor and the District because of the difficulty of fixing the District's actual
damages in the event of delayed submission of Submittals, delayed Substantial Completion or
delayed completion of Punchlist items. The Contractor acknowledges and agrees that the
Liquidated Damages are reasonable and that the Liquidated Damages do not constitute a penalty.
If the liquidated Damages assessed by the District pursuant to the foregoing exceed the
remaining balance of the Contract Price due the Contractor, the Contractor and the Performance
Bond Surety shall be jointly and severally liable to the District for all Liquidated Damages liability of
the Contractor exceeding the balance of the Contract Price.
5. Limitation on Contractor Damages. In the event of the District's breach or default under the
Contract Documents, the damages, if any, recoverable by the Contractor shall be limited to
general damages which are directly and proximately caused solely by the breach or default of the
District and shall exclude any and all special or consequential damages, if any, or any kind, type
or nature. By executing the Agreement, the Contractor expressly acknowledges the foregoing
limitation to recovery of damages from the District if the District is in breach or default of its
obligations under the Contract Documents. The Contractor expressly waives and relinquishes all
rights to any recovery of special or consequential damages from the District including, without
limitation, damages for: (i) lost or impaired bonding capacity; (ii) lost profits arising out of or in
connection with any project or project work, except for the Project which is the subject of this
Agreement; (iii) loss of bidding opportunities; (iv) loss or prospective economic advantage; and (v)
other similar damages, losses or liabilities.
6.
The Contract Documents. The documents forming a part of the Contract Documents consist
of the following, all of which are component parts of the Contract Documents.
Notice to Contractors Calling For Bids
Instructions For Bidders
Bid Proposal
Subcontractors List
Non-Collusion Affidavit
Statement of Bidder's Qualifications
Bid Bond
Roof Project Financial Disclosure Certificate
Bid Addenda Nos. 1, 2, 3 and 4
Agreement
Performance Bond
Labor and Materials Payment Bond
Drug-Free Workplace Certification
General Conditions
Special Conditions
Guarantee
Scope of Work
Specifications
Drawings
Labor Compliance Program
OCIP Insurance Program and Policies
OCIP Forms
7. Acknowledgment and Confirmation.
Contractor acknowledges its receipt, review and
understanding of the Drawings, the Specifications and other Contract Documents pertaining to the
Work. Contractor certifies that the Contract Documents are adequate, feasible and complete for
providing, performing and constructing the Work in a sound and suitable manner for the use
specified and intended by the Contract Documents. Contractor certifies that it has, or has
available, all necessary equipment, personnel, materials, facilities and technical and financial
ability to complete the Work for the Contract Price within the Contract Time and in accordance
with the Contract Documents.
8. No Oral Agreements. No oral agreement or conversation either before or after execution of the
contract shall affect or modify any of the terms or obligations contained in this Agreement or in any
of the documents comprising the Contract Documents.
BORBONINCORPORATED
AGREEMENT DATED: 01·03·13
$169,069.00
ATHLETIC FACILITIES
41 ·251·0283·0·0835·0000·621 0
EIS PROJECT #230043
AGREEMENT
PAGE 2
9. Authority to Execute. The individual(s) executing this Agreement on behalf of the Contractor
is/are duly and fully authorized to execute this Agreement on behalf of Contractor and to bind the
Contractor to each and every term, condition and covenant of the Contract Documents.
CONTRACTORS ARE REQUIRED BY LAW TO BE LICENSED AND
REGULATED BY THE CONTRACTORS' STATE LICENSE BOARD.
ANY QUESTIONS CONCERNING A CONTRACTOR MAY BE
REFERRED TO THE REGISTRAR, CONTRACTORS' STATE LICENSE
BOARD, P.O. BOX 2600, SACRAMENTO, CALIFORNIA 95826
IN WITNESS WHEREOF, this Agreement has been duly executed by the District and the
Contractor as of the date set forth above.
"CONTRACTOR"
BORBONINCORPORATED
"DISTRICT"
By:
~m~~
Wade W. Ellis, CPA
Title: Director of Fiscal Services
By:
--,~~~",,=~... -----c.M.=.L.!~~=_
Title:
_B..L....;n,-",e=s"-,-;""",d<-..:::.uri,-,-,--",,,--_/_
(CORPORATE SEAL)
Attach notary acknowledgment for ali signatures of Prime Trade Contractor. If signed by other than
the sole proprietor, a general partner, or corporate officer, attach original notarized Power of Attorney
or Corporate Resolution.
BOR80N INCORPORATED
AGREEMENT DATED:
$169,069.00
01~03"13
ATHLETIC FACILITIES
41·251·0283-0-0835-0000-6210
EIS PROJECT #230043
AGREEMENT
PAGE 3
01/40/2013 09:51 FAX 714 994 0641
141 001
BORBON INC
Minutes of the Annual Meeting of Shareholders
Of
Borbon, Inc
Date: May 1, 2008
Time: 11:00 A.M.
Place: 7312 Walnut Ave.
Buena Park, CA 90620
Present at said meeting were lhe following:
Cecilia Morales
Susan Fiorentino
Cecilia Morales acted as Chairperson of lhe meeting. Susan Fiorentino acted as Secretary of lhe
meeting.
The Secretary announced lhat lhe meeting was held pursuant to notice as required under lhe
,
bylaws of lhe corporation, or lhat notice had been waived by all directors entitled to receive
notice under lhe bylaws. Copies of any certificates of mailing of notice prepared by lhe Secretary
of lhe Corporation and any written waivers' signed by directors entitled to receive notice of lhis
meeting are attached to lhese minutes.
The purpose of said meeting was to comply wilh lhe requirements of lhe company bylaws by
conducting lhe annual meeting, and to review lhe current status of lhe business and lhe current
financial status of lhe company. Share certificates number·4 and number 5 were presented to
'
Cecilia Morales.
..
01/30/2013 09:52 FAX 714 994 0641
BORBON INC
141 002
Discussion was held on the status of the application to certify the company as a minority and
women owed business.
After reviewing the financial status of the company and the current book of business the meeting
was adjourned.
Dated: May 1, 2008
Cecilia Morales
,6&:zm \&'wl/;;'it;
./
Susan Fiorentino
CERTIFICATE OF SECRETARY
FOR
BORBON INCORPORATED.
a California corporation
I, CECILIA V. MORALES, hereby certifY as follows:
1.
I am the duly elected Secretary of BORBON INCORPORATED., a California
corporation (the "Corporation").
2.
The stock of the Corporation is owned as follows:
Certificate No.
David Morales
Dated: July.BL2006
I
Number of Shares
100% ownership
1J6~~JV.A~
CECILIA V. MORALES
307681.1
· -.~:,...;,..-"
:;\'1',lfl":E
!
....
"'~-,-"
'!!J'·:(tOmi
•. ,
,.
! .,
!l'!", ,:,'\'l:\'f-.t",;,f!j\~ ,";p.)E. _, ( ."ti,:k:F';;;~M1jt,~ "._~_."<,\b.~,, , z , )
M~4."200s
11,54
; "> "_"d",
",~~"h,3>t-""'
,',,,",
'¥'-\~{''';'; '''~'''""YR-d·I,~'.d1i?iMW~5i'1/;,t~:iP.,.tJi."",~"-'0:'' i'\~.'!i;"¥"-'15fi#0";!" ,,~A, "N, '.
NO. 940
CAPl ttL 5\;1$. INC .. 17149840641
06 679391
California
Secre~ry orSUlte
STAn;r.rENT OF 1"'!'Ct~MJi.tloN
!P-w&i!l_ ~'n9!,'!f~:i-~;~ b',:~~~:~
Bo!OOn iOOJIpO""i>d
C0T7S9'i5 .
Plllp,U3nt:.-'tO .
.""'~~~'S;;b:f. ;:;f.L;,.Ei~:c._w;-= p, r e'5 1. den t
~
Bond #: 57BCSGK7871
Premium: $2,173.00
PERFORMANCE BOND
I
KNOW ALL MEN BY THESE PRESENTS that we, Borbon Incorporated, as Principal, and
Hartford Fire Insurance Company"
./ as Surety, are held and firmly bound unto
DESERT COMMUNITY COLLEGE DISTRICT herelnaftey"the Obligee", in the penal sum of One
hundred sixty-nine thousand sixty-nine Dollars ($169,069.00) in lawful money of the United States,
well and truly to be made, we bind ourselves, our heirs, executors, administrators, successors and
assigns, jointly and severally.
THE CONDITION OF THIS OBLIGATION IS SUCH THAT:
WHEREAS, the Obligee, by resolution of its Board of Trustees has awarded to the Principal a
Contract for the Work described as ATHLETIC FACILITIESj Project No. 230043; Bid Package No• ./
011200.24; Bid Package Description: Painting.
WHEREAS, the Principal, has entered into an agreement with the Obligee for performance of
the Work; the Agreement and all other Contract Documents set forth therein are incorporated herein
and made a part hereof by this reference.
WHEREAS, by the terms of the Contract Documents, the Principal is required to furnish a
bond ensuring the Principal's prompt, full and faithful performance of the Work of the Contract
Documents.
NOW THEREFORE, if the Principal shall promptly, fully and faithfully perform each and all of
the obligations and things to be done and performed by the Principal in strict accordance with the
terms of the Contract Documents as they may be modified or amended from time to time; and if the
Principal shall indemnify and save harmless the Obligee and all of its officers, agents and employees
from any and all losses, liability and damages, claims, Judgments, liens, costs, and fees of every
description, which may be incurred by the Obligee by reason of the failure or default on the part of the
Principal in the performance of any or all of the terms or the obligations of the Contract Documents,
including all modifications, and amendments, thereto, and any warranties or guarantees required
thereunder; then this obligation shall ba void; otherwise, it shall be, and remain, in full force and effect.
The Surety, for value received, hereby stipulates and agrees that no change, adjustment of the
Contract Time, adjustment of the Contract Price, alteratlons, deletions, additions, or any other
modifications to the terms of the Contract Documents, the Work to be performed thereunder, or to the
Specifications or the Drawings shall limit, restrict or otherwise impair Surety's obligations or Obligee's
rights hereunder; Surety hereby waives notice from the Obligee of any such changes, adjustments of
Contract Time, adjustments of Contract Price, alterations, deletions, additions or other modifications
to the Contract Documents, the Work to be performed under the Contract Documents, or the
Drawings or the Specifications,
In the event of the Obligee's termination of the Contract due to the Principal's breach or default
of the Contract Documents, within twenty (20) days after written notice from the Obligee to the Surety
of the Principal's breach or default of the Contract Documents and Obligee's termination of the
Contract, the Surety shall notify Obligee in writing of Surety's assumption of obligations hereunder by
its election to either remedy the default or breach of the PrinCipal or to take charge of the Work of the
Contract Documents and complete the Work at its own expense ("the Notice of Election"); provided,
however, that the procedure by which the Surety undertakes to discharge its obligations under this
Bond shall be subject to the advance written approval of the Obligee, which approval shall not be
ATHI.ETIC FACILITIES B#41~251.0283~O.O!i35.00{)O.6210
Pe~f'ORMANCE BOND - SECTION
oosoo
MULTI PRIME-ocrp-AB 1$06 (0T.11)
PERFORMANCE BONO
PAGE1
unreasonably withheld, limited or restricted. The insolvency of the Principal or the Principal's mere
denial of a failure of performance or default under the Contract Documents shall not by itself, without
the Surety's prompt, diligent inquiry and investigation of such denial, be justification for Surety's failure
to give the Notice of Election or for its failure to promptly remedy the failure of performance or default
of the Principal or to complete the Work.
In the event the Surety shall fail to issue its Notice of Election to ObJigee within the time
provided for hereinabove, the Obligee may thereafter cause the cure or remedy of the Principal's
failure of performance or default or to complete the Work. The Principal and the Surety shall be each
jointly and severally liable to the Obligee for all damages and costs sustained by the Obligee as a
result of the Principal's failure of performance under the Contract Documents or default in its
performance of obJigations thereunder, including without limitation the costs of cure or completion
exceeding the then remaining balance of the Contract Price; provided that the Surety's liability
hereunder for the costs of performance, damages and other costs sustained by the Obligee upon the
Principal's failure of performance under or default under the Contract Documents shall be limited to
the penal sum hereof, which shall be deemed to include the costs or value of any Changes to the
Work which increases the Contract Price.
In the event suit or other proceeding is brought upon this Bond by the Obligee, the Surety shall
pay to the Obligee all costs, expenses and fees incurred by the Obligee therewith including, without
limitation, attorney's fees.
IN WITNESS WHEREOF, the Principal and Surety have executed this inslrument this
of January. 20.J}by their duly authorized agent or representative.
,/
~day
Borbon Incorporated
(Print/pal's Corporate Sea!)
(Principal Name)
By:
Gg, Q"
fi
M tfl-(\k~
(Typed or Printed Nama)
Title: _ _ _ _ _ _ _ _ _ _ _ _ _ __
,/
Hartford Fire Insurance Company
(Surely's corporate Seal)
(Surely Nama)
/
(A1tsch Allomey·in-Fae: CertUkat\!)
(415
ATHLETJC FACIUTIE;S 9#41.251.0283.0·0835-0000·&210
PERFORMANCE BOND - SECTION 00600
MULTI PRIMe -DCI? -AB 1606 (07.11)
)~8~36~4~8~58~
_____________________
PeRFORMANce BOND
PAGs2
Contact name, address, telephone number and email
address for notices to the Surety
Mr. Pierre LeCompte
{Contact Nama)
595 Market Street, 5th Floor, San Francisco, CA 94105
(Addrt.llStI)
(415) 836-4858
(Tolophona)
[email protected]
(Ema!! addrasSl)
ATHL~TIC
FACILITIES B#41·251"()283.0.o935·0000·S21 0
PERFORMANce BOND - SECTION 00600
MULTI PRIMe..oCIP-AB 1506 (07,11)
PERFORMANCE BOND
PAGe3
Direct Inquiries/Claims to:
THE HARTFORD
POWER OF ATTORNEY
Bond T·4
One Hartford Plaza
Hartford, Connecticut 06155
call: 888·266·3488 or fax: 860·757·5835)
Agency Code: 57
KNOW ALL PERSONS BY THESE PRESENTS THAT:
141108
~ Hartford Fire Insurance Company, a corporation duly organized under the Jaws of the State of Connecticut
Hartford Casualty Insurance Company, a corporation duly organized under the laws of the State of Indiana
o
o
o
o
o
o
o
Hartford Accident and Indemnity Company, a corporation duly organized under the laws of the State of Connecticut
Hartford Underwriters Insurance Company, a corporation duly organized under the laws of the State of Connecticut
Twin City Fire Insurance Company, a corporation duly organized under the laws ofthe State ofIndiana
Hartford Insurance Company of Illinois, a corporation duly organized under the laws of the State of Illinois
Hartford Insurance Company of the Midwest, a corporation duly organized under the laws of the State of Indiana
Hartford Insurance Company of the Southeast, a corporation duly organized under the laws of the State of Florida
having their home office in Hartford, Connecticut (hereinafter collectively referred to as the "Companies") do hereby make, constitute and appoint,
up to the amount of UNLIMITED
VENETIA G. JOHNSON, KANDACE L. REEVES OF FREMONT CA; CATHER~E A.
PINNEY, NATALIE ANN HORDER OF PETALUMA CA; STACY M. CLINTON, K. DIXON
WRIGHT, NANCY L. WALLIS, DONNALYN REVIS OF SAN CARLOS, CALIFORNIA
their true and lawful Attorney(s)-in-Fact, each in their separate capacity if more than one is named above, to sign its name as surely(ies) only as delineated
above by [8], and to execute, seal and acknowledge any and all bonds, undertakings, contracts and other written instruments in the nature thereof, on behalf
of the Companies in their business of guaranteeing the fidelity of persons, guaranteeing the performance of contracts and executing or guaranteeing bonds
and undertakings required or permitted in any actions or proceedings allowed by law.
In Witness Whereof, and as authorized by a Resolution of the Board of Directors of the Companies on August 1, 2009, the Companies have
caused these presents to be signed by its Vice President and its corporate seals to be hereto affixed, duly attested by its Assistant Secretary. Further,
pursuant to Resolution of the Board of Directors of the Companies, the Companies hereby unambiguously affirm that they are and will be bound by any
mechanlcally appfied signatures applied to this Power of Attorney.
We~ley
W. Cowling, Assistant Secretary
M.
Ross Fisher, Vice President
STATE OFCONNECTICUT}
SS.
Hartford
COUNTY OF HARTFORD
On this 12th day of July, 2012, before me personally came M. Ross Fisher, to me known, who being by me duly sworn, did depose and say: that
he resides in the County of Hartford, State of Connecticut; that he is the Vice President of the Companies, the corporations described in and which executed
the above instrument; that he knows the seals of the said corporations; that the seals affixed to the said instrument are such corporate seals; that they were
so affixed by authority of the Boards of Directors of said corporations and that he signed his name thereto by like authority.
CERTIFICATE
Kathleen T. Maynard
Notal)' Public
My Commission Expires July 31, 20! 6
I, the undersigned, Vice President of the Companies, DO HEREBY CERTIFY that the above and foregoing is a true and correct copy of the Power
of Attorney executed by said Companies, which is still in full force effective as of January 9, 2013
Signed and sealed at the City of Hartford.
Gary W. Stumper,
POA 20J2
Vice President
CALIFORNIA AlL·PURPOSE ACKNOWLEDGMENT
~~~,w.m;
State of California
Countyof __~S~o~n~om~a_______________________
On January 9, 2013
before me,
Date
}
1(. Dixon Wright, Notary Public
Here insert Name and Title of the OHicer
personally appeared _______
S_ta_c-'-y_M_._C_I_in_t_o_n__"'_'____""====_______________________
Name(sj of Signer(s)
who proved to me on the basis of satisfactory evidence to
be the person(s) whose name(s) is/are subscribed to the'
within instrument and acknowledged to me that
he/she/they executed the same in his/her/their authorized
capacity(ies), and that by his/her/their signature(s) on the
instrument the person(s), or the entity upon behalf of
which the person(s) acted, executed the instrument.
I certify under PENALTY OF PERJURY under the laws
of the State of California that the foregoing paragraph is
true and correct.
WITNESS my hand and official eal.
/
Place Notary Seal Above
Signature-ltr.n~",-~~~~==;c-_ _ _ __
OPTIONAL-----------------------Though the information below is not required by law, it may prove valuable to persons relying on the document
and could prevent fraudulent removal and reattachment of this form to another document.
Description of Attached Document
Title or Type of Document: ___________________________________________________________
Document Date: ____________________________________ Number of Pages: _________________
Signer(s) Other Than Named Above:
Capacity(ies) Claimed by Signer(s)
Signer's Name: Stacy M. Clinton
Individual
D Corporate Officer - Title(s):
D Partner - 0 Limited 0 General
lEI Attorney in Fact
D Trustee
D Guardian or Conservator
D Other: _ _ _ _ _ _ __
D
Signer Is Representing: ______
Signer's Name: ____________________________
Dlndividual
DCorporate Officer - Title(s): _________________
DAttorney in Fact
Top of thumb here
DTrustee
DOther: _ _ _ _ _ _ _ _ __
Signer Is Representing: __________
~~~~~""§Y(
©2007 National Notary Association' 9350 De Soto Ave., P.O. Box 2402' Chatsworth, CA 91313·2402- www.NationaINotary.org item 115907 Aeorder:CaIfTolI·Free 1"800·876·6827
y
. THE!!J.
Producer Compensation Notice
HARTFORD
You can review and obtain information on The Hartford's
producer compensation practices at www.thehartford.com
or at 1-800-592-5717.
HR 00 H093 00 0207
© 2007, The Hartford
Page 1 of 1
CALIFORNIA ALL.PURPOSE ACKNOWLEDGMENT
EXf'WZ?:27~
State of California
County of
On
}
0 'fa. Y\~-e
\--11-13
before me,
Dr. " 11 'I't
AY\Y\Q Lo,UYGl
Cat-aves
~ ,I 0 \~,rl I _, ~~:' '"':" ~am"'d Till, ofth, OHl,,,
personally appeared __-,,=,-,"C:....::
'\../!::..:...=l=A..--'I..::....tv-'-'-"uIU.Lb\...'-'I-(;:::~...;,;:;T.;=v~;;;v-- _ _ _ _ _ _ _ __
Date
C
Nama{sro! Slgne~y
be the perso~Mwhose namejsf isjlU9 subscribed to the
!;le1shefthl'1 executed the same in h~ffierfth.ei(iiUthorized
capacity~sl, and that by J:)i$lherftj)eir signature!s} on the
instrument the pe"!on(s}, or the entity upon behalf of
which the persotl(s) acted, executed the instrument.
true and correct.
/
-------------------OPTIONAL------~--------------Though the information below is not required by law, It may prove valuable to persons relying on the document
and could prevent fraudulenf.removal and reattachment of this form to another document.
Title or Type of Document:
DocumentDate:
Pe("'.-fz:;,YVvlCtV)CQ..
\-Cl- /3
~(1 Ad
Number of Pages: _ _ _ _ _ _ __
Lee!! II
Iv\ orcA \es
Signer's Name:
CI,.
o Individual
-I;i<Corporate Officer - Title(s):
Partner - 0 limited 0 General
o Attorney in Fact
Trustee
Guardian or Conservator
o Other: _ _ _ _ _ _ __
'
.
\?,E'i:: i c\evct
o
o
o
RIGHTTHUMSPRINT
OF SIGNER
Top of thumb here
g 2 C
o Individual
o Corporate Officer -
Title(s): _ _ _ _ _ _ _ __
0 Limited 0 General
RIGHT THUMBPRINT
OFSIGNEA
Attorney in Fact
Top of thumb hem
o Trustee
o Other: _ _ _ _ _ _ _ __
o Partner -
o
o
Signer Is Representing: _ _ __
~.Q.
Signer's Name: _ _ _ _ _ _ _ _ _ _ _ _ __
Signer Is Representing: _ _ _ __
WJ§!l.
g:c..
2:. 2 eJC g
Q
s::::;
g:;g;g;;
:@'C _
g &D&2 2M
«:12007 NaUonat Notary Assoclation· 9350 De Solo Ave., P,O.8o>.: 2402.Chalsworlh, CA 91313-2402· www.NationalNolary.org Item 115907 Aeorder:CaUTon-Free 1-80o.87S·6827
DESERT COMMUNITY COLLEGE DISffilCT
Bond #: 57BCSGK7871
Premium: included in perf bond
LABOR AND MATERIAL PAYMENT BOND
if
KNOW ALL MEN BY THESE PRESENTS that we, Borbon Incorporated as Principal, and
'if
as Surety, are held and
firmly bound unto DESERT COMMUNITY COLLEGE DISTRICT hereinafter "the Obligee", in the
penal sum of One hundred sixty-nine thousand sixty-nine Dollars ($169.069.00lji'f lawful money of the
United States, well and truly to be made, we bind ourselves, our heirs, executors, administrators,
successors and assigns, jointly and severally.
THE CONDITION OF THIS OBLIGATION IS SUCH THAT:
WHEREAS, the Obligee, by resolution of its Board of Trustees has awarded to the Principal a
Contract for the Work described as ATHLETIC FACILITIES; Project No. 230043; Bid Package No.
011200.24; Bid Package Description: Painting.
./
WHEREAS, the Principal, has entered into an Agreement with the Obligee for performance of
the Work, the Agreement and all other Contract Documents set forth therein are incorporated herein
by this reference and made a part hereof.
WHEREAS, by the terms of the Contract Documents, the Principal is required to furnish a
bond for the prompt, full and faithful payment to any Claimant, as hereinafter defined, for all labor
materials or services used, or reasonably required for use, in the performance of the Work.
NOW THEREFORE, if the Principal shall promptly, fully and faithfully make payment to any
Claimant for all labor, materials or services used or reasonably required for use in the performance of
the Work then this obligation shall be void; otherwise, it shall be, and remain, in full force and effect.
The term "Claimant" shall refer to any person, corporation, partnership, proprietorship or other
entity including without limitation, all persons and entities described in California Civil Code §3181,
providing or furnishing labor, materials or services used or reasonably required for use in the
performance of the Work under the Contract Documents, without regard for whether such labor,
materials or services were sold, leased or rented. This Bond shall inure to the benefit of all Claimants
. so as to give them, or their assigns and successors, a right of action upon this Bond.
In the event suit is brought on this Bond by any Claimant for amounts due such Claimant for
labor, materials or services provided or furnished by such Claimant, the Surety shall pay for the same
and reasonable attorneys fees pursuant to Califomia Civil Code §3250.
.
The Surety, for value received, hereby stipulates and agrees that no change, extension of
time, alteration, deletion, addition, or any other modification to the terms of the Contract Documents,
the Work to be performed thereunder, the Specifications or the Drawings, or any other portion of the
Contract Documents, shall in any way limit, restrict or otherwise affect its obligations under this Bond;
the Surety hereby waives notice from the Obligee of any such change, extension of time, alteration,
deletion, addition or other modification to the Contract Documents, the Work to be performed under
the Contract Documents, the Drawings or the Specifications of any other portion of the Contract
Documents.
ATHlETIC FACIUTI!:S B#41-251..Q283-0-OS36.o00D.621 0
l.A.SoRiMATtlRIALS PAYMENT BOND - SECTION 00S10
MUlTI PRIME~OCIP-Aa 1506 (07.11)
PAYMENT BONO
PAGE 1
DesERT COMMUNITY COLLE",. DISTRICT
9th
IN WITNESS WHEREOF, the Principal and Surety have executed this instrument this
day of January
• 20.12. by their duly authorized agent or representative.
/
Borbon Incorporated
(PrinCiPal Name)
(princlpal'S Corporafe Seal)
By:
C,(\, Q, '>
/
A.A «\o,,~
(Si!;lnarure)
(Type or Print Name)
Title: _ _ _ _ _ _ _ _ _ _ _ _ _ __
(Surety's Ct:lrpClI1',t/!'·$ool)
/
)
(Attach Attomey·ln~Faol Certlflcatej·'
By:_~,.4lJ""""w.<.._+'_--'-"'-':.......;."""""-'='--"-"""---
(Type or Print Name of Attorney~in-faot)
( 415) _.:::c83:.:6..
-4c::,85:.::8:-._ _ _ _ _ _ _ _ __
(Area Code and TelephonE! Number of surety)
Mr. Pierre LeCompte
(Con"'o\ Name)
595 Market Street, 5th Floor, San Francisco, CA 94105
(Address)
(415) 836-4858
(Telepl1one)
[email protected]
(Email address)
~ATHLeTlC FACII..£TIES 8#41 ~251-0283·0·08a5..()tlOI).$21 ()
t.AooRlMATERfAlS PAYMENT BOND - SecT/ON OOS10
MULTIPRIME-OCIP-AB 1506(07,11)
PAYMENT BOND
PAGE 2
Direct Inquiries/Claims to:
POWER OF ATTORNEY
THE HARTFORD
Bond T-4
.One Hartford Plaza
Hartford, Connecticut 06155
call: 888·266·3488 or fax: 860·757·5835)
Agency Code: 57
EJ Hartford Fire Insurance Company, a corporation duly organized under the laws of the State of Connecticut
D
D
D
D
D
D
D
141108
/
Hartford Casualty Insurance Company, a corporation duly organized under the laws of the State of Indiana
Hartford Accident and Indemnity Company, a corporation duly organized under the laws ofthe State of Connecticut
Hartford Underwriters Insurance Company, a corporation duly organized under the laws of the State of Connecticut
Twin City Fire Insurance Company, acorporation duly organized under the laws of the State of Indiana
Hartford Insurance Company of Illinois, a corporation duly organized under the laws of the State of Illinois
Hartford Insurance Company of the Midwest, a corporation duly organized under the laws of the State of Indiana
having their home office in Hartford, Connecticut (hereinafter collectively referred to as the "Companies") do hereby make, constitute and appOint,
up to the amount of UNLIMITED
VENETIA G. JOHNSON, KANDACE L. REEVES OF FREMONT CA; CATHERIN~ A.
PINNEY, NATALIE ANN HORDER OF PETALUMA CA; STACY M. CLINTON,/K. DIXON
WRIGHT, NANCY L. WALLIS, DONNALYN REVIS OF SAN CARLOS, CALIFORNIA
their true and lawful Attorney{s)"in"Fact, each in their separate capacity if more than one is named above, to sign its name as surety(ies) only as delineated
above by [2:1, and to execute, seal and acknowledge any and all bonds, undertakings, contracts and other written instruments in the nature thereof, on behalf
of the Companies in their business of guaranteeing the fidelity of persons, guaranteeing the performance of contracts and executing or guaranteeing bonds
and undertakings required or permitted in any actions or proceedings allowed by law,
In Witness Whereof, and as authorized by a Resolution of the Board of Directors of the Companies on August 1, 2009, the Companies have
caused these presents to be signed by its Vice President and its corporate seals to be hereto affixed, duly attested by its Assistant Secretary, Further,
pursuant to Resolution of the Board of Directors of the Companies, the Companies hereby unambiguously affirm that they are and will be bound by any
mechanically applied signatures applied to this Power of Attorney,
Wesley W, Cowling, Assistant Secretary
M. Ross Fisher,
Vice President
STATE OF CONNECTICUT}
SS.
Hartford
COUNTY OF HARTFORD
On this 12th day of July, 2012, before me personally came M. Ross Fisher, to me known, who being by me duly sworn, did depose and say: that
he resides in the County of Hartford, State of Connecticut; that he is the Vice President of the Companies, the corporations described in and which executed
the above instrument; that he knows the seals of the said corporations; that the seals affixed to the said instrument are such corporate seals; that they were
so affixed by authority of the Boards of Directors of sa'id corporations and that he signed his name thereto by like authority.
~~~
.~.
Kathleen T. Maynard
Notary Public
My Commission Expires July 31, 2016
CERTIFICATE
I. the undersigned, Vice President of the Companies, DO HEREBY CERTIFY that the above and foregoing is a true and correct copy of the Power
of Attorney executed by said Companies, which Is stm in full force effective as of January 9 I 2013
j
Gary W. Stumper, Vice
POA 2012
President
CALIFORNIA ALL·PURPOSE ACKNOWLEDGMENT
~~~~~
State of California
County of _-'S:.:o"'n.::om=a_ _ _ _ _ _ _ _ _ __
On January 9, 2013
Date
personally appeared
before me,
}
K. Dixon Wright, Notary Public
Here Insert Name and Tille of the Officer
~
___-=S.::ta::.:c"'-y-=M::::....C=Ii::.nt:..:o.::n_ _ _ _===="'____________
Name(s) of Signer(s)
be the person(s) whose name(s) is/are subscribed to the
he/she/they executed the same in his/her/their authorized
capacity(ies), and that by his/her/their signature(s) on the
instrument the person(s), or the entity upon behalf of
which the person(s) acted, executed the instrument.
true and correct.
WITNESS
/
Signature-lA~~....li~:."r;;,c=:;-;:;::;::==--~-Signature 01 Notary Public
---------------------OPTIONAL-----------------------Though the information be/ow is not required by law, It may prove valuable to persons relying on the document
Title or Type of Document: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ __
Document Date: ___________________ Number of Pages: _ _ _ _ _ _ _ __
Individual
ICJ Corporate Officer - Title(s):
lEI Attorney in Fact
D Trustee
D Other: _ _ _ _ _ _ __
o
Signer's Name: _ _ _ _ _ _ _ _ _ _ _ _ _ __
o Individual
DCorporate Officer - Title(s): _ _ _ _ _ _ _ __
DAttorney in Fact
DTrustee
DOther: _ _ _ _ _ _ _ __
o
~~~~~QWb3~
©2007 National Notary Associatlon' 9350 De Solo Ave" P.O. Box 2402 'Cha!swotih,CA 91313-2402' WW'W.Nallona!Notary.org !lem #5907 Aeorder:CaIIToll-Free 1-800-876-8827
Producer Compensation Notice
You can review and obtain information on The Hartford's
producer compensation practices at www.thehartford.com
or at 1-800-592-5717,
HR 00 H093 00 0207
© 2007, The Hartford
Page 1 of 1
CALIFORNIA ALL.PURPOSE ACKNOWLEDGMENT
~7??~
State of California
County of
On
\.-
}
0 '((A Vl~-e
II-I;;
Dale
personally appeared
before me
'
"
AvwvJ.. Lo.UYG\ Ca'2a YeS
Here Insert Name and Title of the Officer
_---:>C"--!'e,", ~,: :C: .!.\,-,\."-Ov",-,~!-".~",O:.!.:V(",l",,\.Q.S~·
\
;;;;;.)~!=-.w;--------
Name{ljY@' Signe:~i)
be the person~ whose namep;f is/~ subscribed to the
within' instrument and acRnowledged to me that
I;Ie/she/thj}/ executed the sarT)e in his/her/their authorized
capacity\jes). and that by tJiS/her/~ir signatur;ls) on the
instrument the person(s-y' or the entity upon behalf of
which the person{jyacted. executed the instrument.
•
true and correct.
-------------------opnONAL----~~----~~------
Though the information below is not required by Jaw, it may prove valuable to persons relying on the document
Title or Type of Document:
Document Date:
\'-
l abo r
OIl1ci
rJcOOIC,t ( PAl-IVY! etllt-Bofldv
9-- 12>
1
Number of Pages: _ _ _ _ _ _ __
Capacity(ies) Claimed by Signer(s}
IvlOV-Ales
Signer's Name:CeCill'(1v
o Individual
o Corporate Officer - Title(s):
o Partner - 0 Limited 0 General
o Attorney In Fact
Trustee
o Other: _ _ _ _ _ _ __
o
o
RIGHT THUMBPRINT
OF SIGNER
Top of thumb here
Signer's Name: _ _ _ _ _ _ _ _ _ _ _ _ __
o Individual
o Corporate Officer - Tltle(s): _ _ _ _ _ _ _ __
o Partner - 0 Limited 0 General
RIGHTTHUMBPAINT
OFSIGNEA
o Attorney In Fact
Top of thumb here
o Trustee
o Guardian or Conservator
o Other: _ _ _ _ _ _ _ __
~ 2 Q;>g;;;:gz:g """.ZiC, • ,2 2~:C;~ g:;;;:gz:g
2~
<l!l2007 Nal10nal Notary Association. 9350 De Solo Ave., P.O. Box 2402 .Chatsworth, CA 91313·2402" www.NationalNotary.org Item #5907 Roorder;CaIlToU·Free 1-800-876-6827
,----------------------------'--"'---"
CERTIFICATE OF LIABILITY INSURANCE
1/9/2013
6~~T~~~:~~C~6~iSN~~~~I~~:T~~r~E~RO~~~~~~~~~I~~~~~; :X~~~~~i~~T~~ ~~~T~O~~:GT~~FFOR;;ED~BY THE POLl6~~
BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED
REPRESENTATIVE OR
AND THE CERTIFICATE HOLDER.
:~,~:.m' ~"
u,~ ~~rm ~
...:::u,
," lithe,
, holder is ~!'
"V"~h
, the
I must be
"
,v,<lS '
~,.'
! pol!cy, ....<>. ~'<' •.':
I
may require an endorsement. A statement on this certificate does not confer rights to the
t'lilti
:~~::::~~umsuch
~~~~~,O~A~C,'C~,=========]II~~~[;,~~~rnQ==~
KPD
03,00 SW Greenburg Rd Ste 200
'v"lo"v OR 97223
!
INSURED
lo.
'
I
NAle #
I
;Ins Co
. Fire lno"'~ne~ Co,
I Union Fire
BORB01C
~~~a
30104
19682
ft \)..- f- V/
f!1, Y- V
,,
... ,,"'"
'NIIMRFR~
I Nil
iNH6fc~T~gG~~~~;T~~~~J~~GJ;NY OF,
,_T~~;6~ CONDI;,~~V~FB~W~ l~~~~!~ 6~~'2~~E~DO~C~~~TA~~/HE :~:p~~i ~gL~~6~~~~
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, :~~.~~~~;~;;;.~ AFFORDED BY T,:j';:'~b~~CI~S DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. L'''''' 0 onv,"" MAY HAVE BEEN ~ ~~LAi,''"M=,S,r---------------I
IA'rfk'
TYPE OF'
POLICY NUMBER
tc---
Fovv, «..
11112014
b-=:JCLAIMS'MADE
EJ
LIMIT:
~Ace,
~
0."'"0", LIABILITY
IX
~
~~
1"1/2013
OCCUR
nno
,,,
$10,000
1 MED EXP (AnY0",p,,,on)
$0 d.d,
_& ADV INJURY
1-
nnn non
GENERAL
Fl~~LlCY Ix I~~R: APn
S
:;;
poon,
1'/'/2013
111/2014
I
no
'300,000
<?
'CTS,
, AGG
nno non
,
~;n;",roro"c1'1'"cJm"
..".-+,,-,n-nn,n r - - - I I
"ODILY
I $":::> U
BODILY
I' 'P', l'~ Y
I'
r~~E=~T1~--~~~~~~I~'~1
1'11/20'3
11112014.;
~ii~~::~~i_~~~-----i11~/1/2013,-r"1~m14~~~ROOT,I'Im.IT~"~-----1
I~i
! "
-EA
nnn nnn
' " nnn nnn
,POLICY LIMIT ,
$1
nnn nnn
OF OPERATIONS I LOCATIONS I VEHICLES (Attach ACORD 101, Additional Remarks Schedule, If more space Is requIred)
1~~!di!lon"aa,IIJ,n;~~~;.~:",~
I
,
does not apply to the Worker's Compensation Coverage.
i
I
Athletics Facilities EIS#230043, Desert Community College District and ProWest PCM, Inc dba ProWest
;,vhiii~',"ctv .. are i"v,""c" as additional insureds per form HS2480 0605, Excess Liability policy follows the General Liability and the auto
!E:
..,
CERTIFICATE HOLDER
CANCELLATION
Desert Community College District cia Statewide
Educational Wrap Up Program (SEWUP)
,
2355 Crenshaw Blvd Suite.200
Torrance CA 90501
~
ACORD 25 (2010/05)
SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE
THE eXPIRATION DATe THEREOF, NOTICE WILL BE DELIVERED IN
ACCORDANCE WITH THE POLICY PROVISIONS.
© 1988-2010 ACORD CORPORATION. All rights reserved.
The ACORD name and logo are registered marks of ACORD
' # 52UENQT2228
Borbon Polley
j
THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.
ADDITIONAL INSURED ANDI
RIGHTS OF RECOVERY AGAINST OTHERS
This endorsement modifies insurance provided under the following:
BUSINESS AUTO COVERAGE FORM /
A. Any person or organization whom you are required by contraci; to name as additional insured is an
"insured" for LIAS ILiTY COVERAGE but only to the extent that person or organization qualifies as an
"insured" under the WHO IS AN INSURED provision of Section II - LIABILITY COVERAGE.
S. For any person or organization for whom you are required by contract to provide a waiver of subrogation,
the Loss Condition - TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US is applicable.
Form HA 991301 87 Printed in U.S.A.
Prinla: Express'"
Commercial Exc.ess Liability Policy With ¢risisResponse'"
DECLARATIONS
rh~
D.
company i$suing thi's policy is, hidicated py ah 'uX" in th$' box to the left of me. cor:nP?ny,ls name.
[j
American'l1Qme.Assurahce Company'
o ·C"hat1fs CasualtY ·c.ompany
Cl
o
o
IIIlno!,s NatiC!nallnsur.~nce' Company
I~ Nati!:mal Union FIre Insurance. Cpmpany,of Pl.~burgh, Pa"
o
o
Cbartl,$ Pro:paJ1Y 'C.asuaity· Compilny
ChmmaTe-a & In'dustrY rns4ra)"ica ~bmpany
'$raniia, 'S"tate Insure'nee: Cort!pany
New H"anips.hire' IhSurance C.ompanV
"rna Ihsl!rat;1C~ C"ompt'!ny of the StatB of'Pennsylvanla
(each of the ab~ve qeing, a 'C'ppltal stock company>
Ad:minlstr.live/Mallln:g Addr.e"s: 175 Water $treet, Ne'" '(orl" NY 1003~
Telephone No .• 212-458-500Q
r
policy NUMEl.ER:8E
I,
I
019070516
ITEM 1. NAMEDINS.URED:
MAIL.ING ADOR·ESS:
if
I'lENEWAlOF': 080575475
1l0i'lBON INCORPORATED /
.
7312 WALNUT AVE
BUENA PARK j .{)A9062ce1760
1
ITEM2: POLICY PllRIO,D: FR0IV!:. January 1.2013
TO: january 1,2914
(At 12:01A.M.... ternd.rd time, .'the add1e •• o·f the Named Insured stated abolie.l
ITEM3. LliVII'FS O·F INSURANCE
The Limits of In$~n:inc'et sUbfecUo the t~t'ms 6fthis ptil!QY, a'ra!
A. $10;000,000
S.• :$1.0,0.00,000
C. $'10/000,000
Eaoh Dcqur'e'nc.
Sa·o.erill Aggre:g.ate (in accer,dance, w1h S'eqtion IV. limits of'lnsurance)
Pro:ducts~Complgted, Operatltms A,9gregate (In 'accord'ance with Section IV. 'Limits of IhSurariCe)
D. :$250';000
Ctis'jsRe'5poJ~se
E. $50,000
E",ces'S' Ca"su·ally CrlsisFund Limiloi'lnsur-an,ce
Sublimit oJ Insur.a"nc,e
ITEM 4 •.SCHEDUbE,D UNDERLYING INSURANCE _ S.".$cheduleoi'.Underlylng Insuran.".
ITE;M·5, PREMIUM AND PREMIUM COMPUTATION
ESTiMATED TOTAL ANNUAL EXPOSURE
RATES PER
MINIMUM PR.EMIUM
ADVANCE PREMIUM
FLAT
ITEME;, THIS POLICYINGLUDESTHESE ENDORSEMENTS AT INCEPTION DATE!. SEE· ArtACHEO SCHEDULE
PROOUCER NAME, CRC INSURANCE SERViCES INC
ADDRESS:
·1191SEClONDAVE, STE .1610
SEATTLE, wA 98101
Christopher G. Kopse(
Auihorized Repra,sentative or
Courtler.lsnalUra (Where Applioable I
9(JZ68 (11/09)
AH2706.
.
l~s.u.e Date:
12/28/12
"
:!
A
iJ
l'l~,
S,CHEDULE OF UNDERL VING INSURcANCE
Ii
Ii
Ii
"
ro.:
n
11
I~suep
E
By: NATIQ'NALUNIONFIRE INSURANcE t:OMPANYOP piTTsBURGH, PA
Ii
I)
r
TYPE OF PQIJOY
ORC.DVERAGE
INSURER{' POLICY NO.
AND POL CY PERIOD
GENERAL LIAElILITY
Hartford
$1,000,000
UMl;rvlKiters
Insuranoe Company
PER OC,CURRENCE
1;</31/12
GIONERAL AGGREGATE
SORSON INCORPORATED
Polioy Number: SE
019070516
I
if
01/01114
LIMITS
$2,OOQ,000
$2f OOO,000
PRODUCTS & COMPLET'ED OPS.
AG'GREGATE
$2,000,000
PER PROJECT GENERAL AGGHEGATE
Defense EXpenses are
in addition to. 'the limit
AUTO LlAB ILITY
.;
Hartford Fire
lr1s\,Jrancl; Cornp$ny
12/31/12
$1,000,000
COMB,INEOSING,LE LIMIT
12/31/13
Defs'nS"€i' E.xpense-s are
in addition to. 'the limit
eMpLOYERS LlAI3IL1TY
Hartfot!:!
$l,QOOfOOD
Underwilers
Insu"u]oe C<;impany
SODILY INJURY.BY ACCIOgNT
12131/1.2
01/01/14
S601L YINJURY BY DISEASE(EACH
$1,000,000
EMP~OYEE)
$1,000,000
E\OO,I~Y INJURY BY
DiSEASE(POLfCY LIMITS)
Defens~ E-Xp~nses
are
in addition to the iimit
E'MP~OYEg BEN,EFITS LlASILITV
Hartford
$1,000,000
UndervIK.ite.rs
Insuranoe Company
EACH CLAIM
12/31112
01/01/14
AGGl1E(>ATE
$1,000,000
Oefense.EXpenses. "Ie
in addition to 'the limit
l1e,tre Date
12/31/09
l)NoSCH (&/99)
AH0006
SCHEDULE 01' UNDERLYING INSURANCE
IssulOCf to, BORSOJllINCORPORATED
PolioyNumber: BE
019070516
By: NArIONAL,UNION FIRE INSURANQI' COMPANy OF PITTSSURGH, PA.
tyPE OJ: POLlCY
ORCOIlERAtlE
INSURER'r POL,ICYNO.
AND POL C·Y PERIOD
:GhristdRher.G--· !(opser
AUTHQi'UZED REPRESEiIITATl1lE
UJIlD'sCH (5/99)
AHOOOa
SCHEDULE 0F l:lNDERL YING.INSURANCE
REVISION N0. 1
Policy Number: BE
IssuMtb: BORBON .!NCORPORAtED
01901051B
l'Iy! NATIQNAL VNIQN FrR,E Jl)lS!JRANCE COMPANY OF PITTSBURGH, PA.
TYPE d.l' POLICY
~~J1~5~rly'l~~C~)ONDO'
GENERAL LIABILIty
Hartfqrd
Underwiters
1~$ui~tiCe Company
01 101 11:!
01/01114
$1,000,000
PER .oCCURRENCE
$2,.000,.000
GENE'RAL AGGRi:GATE
$2,000;000
PRODUCTS & CO.MPLEtED egs.
AGGREGAtE
$2,000,000
PER PROJECT GENERAL AGGREGAtE
Defense ExpenSes are.
in addition to the limit
AUTO LIABility
Hartford Fire
.Insurance Company
01101/13
$1,000,000
COMBINED SINGLE LIMit
QR cO\7ERAGE
LIMITS
01101114
Defense Expenses are
in addition tb the
eMPLOYeRS LIABILITY
lirilit
Hartford'
Underli\filers
Insurance Company
01/0111S
BOpILY.INJl)RYBY DI$EASE(E.ACH
01/01114
EMPLOYE~)
$1,000,000
i30DILY INJURY BY ACCIDENT
$1;obo,ooO
$1;000;000
BODILY INJURY BY
DISEASEIPOUCY LIMITS)
Defense Expenses'sre
in "ddi'lion to the limit
EMl'LOYeE BENEFITSLIABJUTY
Hartford
Underwiters
hisuiance Company
1213111,2
01101114
$1,000;000
EACH CLAIM
$1,000;000
AGGREGATE
Defimse Expenses. ere
iii addi'lion to the·lim\t
RetroDate
12/31109
UNOl;iCH (51991
AH0006
SCHEDULE OF UNOERl YlNG INSUI'lANCE
REVISION NO.1
EFFECTIVE: 01(14113.
Issued Ie: BORBON INCORPORATED
Felicy Number: BE
019070516
By: NAtIONAL UNION FIRE INSURANCE C;OM!7ANY OF .PITTSBURG H, PA.
TYPE OF POlI.CV
OR COVERAGE
INSURER[ POLICY NO.
AND POL tY PERIOD
Christonher G. Kgoser
AUTHORIZED REPRESENTATIVE
UNDSCH(J;/S9)
AHOOO6
DESERT COMMUNITY COl-LEGE DISTRICT
810 PROPOSAL
TO:
DESERT COMMUNITY COLLEGE DISTRICT, a California Community College District,
acting by and through its Board of Trustees ("the District').
barron -::ttl CCYfE;V'C.A..:.t-d
FROM:
(Name of Bi
er)
hla \\'\~t- Aver\{A£(Address)
!SMAct.., pCI r\L. , Cft ClQCe 1'-0
'"13 [ 2-
(City, State, Zip Code)
hJ\4) qG\q-O\ TO
<.
(Telephone).
ClkQ
@.
(l iIJ) qCJLi-bLe L/I
L
•
bDnJbVl.
(Teiecopier)
O.f;r
(E-Mail Address of Bidder's Representative(s»
SUS on J1(xevyhn 0
(Name(s) of Biddets Authorized Representative(s»
PROJECT: ATHLETIC FACILITIES
PROJECT NO: 230043
BID PACKAGE NO.:
011200.24
BID PACKAGE DESCRIPTION: All Painting and associated work as defined in Section
011200.24 Scope of Work- Painting
1.
Bid Proposal
1.1
Bid Proposal Amount. The undersigned Bidder proposes and agrees to perform the
Contract including, without limitation, providing and fumishing any and all of the labor,
materials, tools, equipment and services necessary to complete in a workmanlike
manner all of the Work and other obligation required by the contract documents .for
the sum ~
•
j
iJ..hJl'\iYle·~W\iiSqI1d
I'} I
Dollars
a .'
Ol1e UI1dreC5
t\
"
,
I
Si::lMJ Yle uml avs
. DO ).
The Bidder confirms that it has checked all of the above figures and understands that
neither the District nor any of its agents, employees or representatives shall be
responsible for any assumptions, errors or omissions on the part of the undersigned
Bidder in preparing and submitting this Bid Proposal.
Bidder includes in the Bid Proposal Amount the following Allowance{s):
ALLOWANCE NO.1: $9,000.00
Include an allowance of Nine thousand dollars ($9,000.00) for additional work
associated with this trade required during the progress of the work.
ATHlernC FACJLmES sff41~251-0835-0000
BID PROPOSAL- SECTION 00.350Q
MULTI PR1ME-OCIP -AS 1506 (07.11)
SID PROPOSAL PAGE 1
PAINTING
1.2
Acknowledgment of Bid Addenda. The Bidder confirms that this Bid Proposal
incorporates and is inclusive of, all items or other matters contained in Bid Addenda
issued by or on behalf of the District.
'~ Addenda Nos. 1,2.·?, Y
(initial)
received, acknowledged
and incorporated into this B(d Proposal.
1.3
Alternate Bid Items. The Bidder's price proposal(s) for Alternate Bid Items of the
above-identified Bid Package is/are set forth in the form of Alternate Bid Item
Proposal included herewith,
1.4
Unit Price Items. The Bidder's price proposals for Unit Price Items of the aboveidenlified Bid Package are set forth in the form of Unit Prices included herewith.
2.
Documents Accompanying Bid Proposal. The Bidder has submitted with this Bid
Proposal the following: (a) the required Bid Security; (b) Subcontractors List; (c) Statement of
Qualifications; (d) Non-Collusion Affidavit; and (e) Title Page and Table of Contents of Injury
& Illness Prevention Program. The Bidder acknowledges that this Bid Proposal and other
documents accompanying the Bid Proposal are complete, accurate and true; incomplete,
inaccurate or untrue responses or information provided herein shall be grounds for the
District to reject this Bid Proposal for non-responsive.
3.
Bidder Certification of Compliance With Minimum OCIP Requirements.
The
undersigned Bidder certifies to the District that the Bidder complies with the Minimum OCIP
ReqUirements set forth in Paragraph 15 of the Instructions for Bidders. By the initials of the
Bidder's authorized representative to the following, Bidder certifies that:
.£.. Within
the last five (5) years, the Bidder has not committed any serious and/or willful
CAL-OSHA violations under Labor Code §§6300 et seq.
if The Bidder maintains a current IIPP conforming to the requirements of Labor
"(inilial)
(initial)
(Initial)
Code §3201.5 or Labor Code §61101.7 and a copy of the Title Page and Table of
Contents of the Bidder's IlPP is submitted concurrently with this Bid Proposal.
Bidder has an average Workers' Compensation Experience Modification Rate
(EMR) of 1.25 or less over the last five (5) years.
The Bidder acknowledges that the foregoing certifications are subject to verification by the
District. If upon such verification, it is reasonably determined by the District that the
foregoing certifications are not true and correct, the Bid Proposal of the Bidder is subject to
rejection for non-responsiveness as a result thereof. The Bidder further acknowledges that if
the Bidder does not or cannot verify the Bidder's compliance with each of the foregoing, the
Bid Proposal of the Bidder is subject to rejection for non-responsiveness.
4.
Award of Contract. If the Bidder submitting this Bid Proposal is awarded the Contract, the
undersigned will execute and deliver to the District the Contract in the form attached hereto
within five (5) days after notification of award of the Contract. Concurrently with delivery of
the executed Agreement to the District, the Bidder awarded the Contract shall deliver to the
District: (a) Certificates of Insurance eVidencing all insurance coverages required under the
Contract Documents; (b) the Performance Bond; (c) the Labor and Material Payment Bond;
(d) the Certificate of Workers' Compensation Insurance; and (e) the Drug-Free Workplace
AlHLSTIC FAClJ..mES 6#41-251·0a~5·0000
BID PROPOSAL. - SECTION 003500
MULTIPRIME-OCIP-AB 1506 (07.11)
BID PROPOSAL PAGE 2
PAINTING
Certificate. Failure of the Bidder awarded the Contract to strictly comply with the preceding
may result in the District's rescission of the award of the Contract and/or forfeiture of the
Bidder's Bid Security. In such event, the District may, in its sale and exclusive discretion
elect to award the Contract to the responsible Bidder submitting the next lowest Bid
Proposal, or to reject all Bid Proposals.
5.
Contractors License. The undersigned Bidder is currently and duly licensed in accordance
with the California Contractors License Law, California Business & Professions Code §§7000
et seq., under the following clarSificatiOn(S}C-33 bearing License Number(s}3"SIS5'] ,
with expiration date(s} of5\31JY . The Bidder certifies that: (a) it is duly licensed, in the
necessary class(es), for performing the Work of the Contract Documents; (b) that such
license shall be in full force and effect throughout the duration of the performance of the
Work under the Contract Documents; and (c) that all Subcontractors providing or performing
any portion of the Work shall be so properly licensed to perform or provide such portion of
the Work.
6.
Agreement to Bidding Requirements. The undersigned Bidder acknowledges and
confirms its receipt and review of and agreement to the bidding requirements set forth in the
Project Bid and Contract Documents. In accordance with California Civil Code § 1717,
Bidder expressly acknowledges and agrees that in the event that Bidder institutes any legal
or equitable proceedings in connection with this Bid Proposal and the District is named as a
party thereto, the prevailing party(ies) shall recover from the other party(ies), as costs, all
attorneys' fees and costs incurred in connection with any such proceeding, including any
appeal arising therefrom. This attorney fee provision shall be limited to legal or equitable
proceedingiS arising out of a bid protest and shall not extend to or have any force and effect
upon any Contract for perfonmance of the Project work or otherwise create or expand either
party's rights and obligations under the SiQ and Ccntract Documents.
~'Y7 ~ r~o
Date:
'Signature
7.
11- W--/2-
Acknowledgment and Confirmation. The undersigned Bidder acknowledges its receipt,
review and understanding of the Drawings, the Specifications and other Contract Documents
pertaining to the proposed Work. The undersigned Bidder certifies that the Contract
Documents are, in its opinion, adequate, feasible and complete for providing, performing and
constructing the Work in a sound and suitable manner for the use specified and intended by
the Contract Documents. The undersigned Bidder certifies that it has reviewed the Bid
Schedule and confirms that the Contract Time is a reasonable period for performing and
achieving Substantial Completion of the Work.
The undersigned Bidder certifies that it has, or has available, all necessary equipment, personnel,
materials, facilities and technical and financial ability to complete the Work for the amount bid herein
within the Contract Time and in accordance with the Contract Documents. ,
By:
b..coCVJ"7 ~'t ~ ,
IS' 1(/1
.-r:-.'.
~I V\, riO v-e.I/(,\1 \I)
(Signature)
(Corporate Seal)
\..
Title:
ATHt.ETIC FACII..ITlES e#41·2S1·OS35·0000
. SIO PROPOSAL- SECTION 003500
MIJt.TIPRJf~!:-OCIP-AB
1506 (07.11)
.
0
(T¥ped or Printed Name)
S
,€.CVe:.::!1;lf
1
810 PROPOSAL PAGE 3
PAINTING
,nes.IIT COMMUNI'N COLLI!Ge DISTRICT
BID BOND
KNOW Ar..r.. MElli 8Y THEse p~I:!SeNTS that we, Hartford Fire Insurance Company
,
as Surety and Borbon Incorporated
, as Principal, are jointly anp severally,
along with their respective heirs, executors, administrators, successors ,and assigns, held and firmly
bound unto DESERT COMMUNITY COLLEGe DISTRICT, hereinafter ",the Obligee," for payment of
the penal sum hereof in lawfUl money of the United States, as more particularly set forth herein.
THe CONDITION OF THIS OBLIGATION IS SUCliiTHAT:
WHEREAS, the Principal has submitted the accompanying Bid Pnoposal to the Obligee for the
Work commonly described as the ATHLETIC FACILITIES; project No. 230043, Bid Package No.
011200.24 aid Package Description Painting.
WHEREAS, subject to the terms of this Bond, the Surety is firmry bound unto the Obligee in
the penal sum of t~m percent (10%) of the maximum amount of the Bid Proposal submitted by the
Principal to the Obligee, as set forth above.
NOW THEREFORe, if the Pril1cipal shall not withdraw said Bid Proposal within the period
specified therein after the opening of the same, or, if no period be spadfied, for sixty (80) days after
opening of said Bid Proposal; and If the Prine/pails awarded the Contract, and shall within the period
speCified therefor, or if no period be specified, within five (5) days after the prescribed forms are
presented to him for signature, enter Into e written contract with the Obligee, In accordant:.<! with the
Bid Proposal as accepted and give such bond(s) with good and sufficient surety or sureties, as may
be reqUire<!. for the faithful performance and proper fulfillment of such Contract and for the payment
for Jabor and materials used for the performance of the Contract, or in Hie event of the withdrawal of
said Bid Proposal within the period specIfied for the hOlding open of the Bid Proposal or the failure of
the Principal to enter into suoh Contract and give such bonds wIthin the tima specified, If the Principal
shall pay the Obligee the difference between the amount specified in said Sid Proposal and the
amount for which the Obligee may procure the required Work and/or supplies, If the latter amount be
in excess of tlie forrner, together with all c:o~ts incurred by the Obligee in again calling for Bids, then
the above obligation shall be void and of no effect, otherwise to remain in full force and effect.
SUrety, for value received, hereby stipulates and agrees that no change, extension of time.
alteration Dr addition to the terms of the Contract or the Call for Bids" the Work to be performed
thereunder, the Drawings or the Speolfications accompanying the same, or any other portion Of the
Contract Documents shall in no way affect its obllgatioh$ under this Bond. and It does hereby waive
notice of any such change, extension of time, alteration or addition to the terms of said Contract, the
Call for Bids, the Work, the Drawings or the Specifications, or any other portion of the Contract
Documents,
In the event suit or other proceeding is brought upon t~is Bond by the Obligee, the Surety shall
pay to the Obligee all costs. expenses and fees Incurred by the Obligee In connection therewIth
including, without limitation, attorney's fees.
A'tkU!'tIC FAmun~s e#41-261.oS3:5·0000
Btc J!(l~O $ICTJON 003000
MULTIPRIMe-OCIP-A~
,sue (07.11)
!lIP IlOND F'I\G~ 1
PAINl'ING
Dl!SERT COMMU~ITY COLLEG~ OIS'!JIICT
16th
IN WITNESS WHEREOF. the Principal and Surety have executed this instrument this
day of November ,:mg by their duly authorl~ed agents or representatives,
Borbon Incorporated
Susan Fiorentino,
TItle: _ _ _ _ _
~
SecretaRY
_ _ _ _ _ _ _ __
Stac
(..i1L) 836-4858
lAta COt!a ,!'t',l r,laphono NlJmbltt or BIJIIlIY)
Pierre LeCompte
595 Market Street, San Francisco, CA 94105
(415) 836-4858
[email protected]
A7HL!r!C FAOIUTlM at41-2a1~O(l35·0000
Ulet BONO $ecTIQN 003000
B,O BOND rAG. ~
MULTI PR'M~-OC'P -AS 1.OS (07,111
PAINTInG
Direct InquirIes/Claims to:
POWER OF ATTORNEY
D
D
D
D
D
D
D
BOND, T-4
P.O. BOX 2103, 690 ASYLUM AVENUE
HARTFORD, CONNECTICUT 06115
call: 888-266·3488 or fax: 860-757-5835)
Agency Code: 57 -141108
rn
THE HARTFORD
Hartford Fire Insurance Company, a.corporation duly organized under the laws of the State ofConnccticut
Hartford Casualty Insurance Company, a corporation duly organized under the laws of the State ofTndiana
Hartford Accident and Indemnity Company, a corporation dilly organized under the laws of the State of Connecticut
Hartford Undervvriters Insurance Company, a corporation duly organized undcrthe laws of the State of Connecticut
Twin City Fire Insurance Company, a corporation duly organized under the laws of the State oflndiana
Hartford Insurance Company of Illinois, a corporation duly organized under the laws of tile State of Illinois
Hartford Insurance Company of the Midwest, a corporation duly organized under the laws of the State oflndiana
having their home office in Hartford, Connecticut (hereinafter collective!y referred to as the "Companies") do hereby make, constitute and appoint,
up to the amount of Unlimi ted
venetia G. Johnson, Kandace L. Reeves of Fremont CAl Catherine A. Pinney,
Donnalyn Revis, Natalie Ann Horder of Petaluma CAl Stacy M. Clinton, K. Dixon
Wright, Nancy L. Wallis
their true and lawful Attorney{s}-in-Fact, each in their separate capacity if more than one is named above, to sign its name as surety(ies) only as
delineated above by [gJ, and to execute, sea! and acknowledge any and aU bonds, undertakings, contracts and other written instruments in the
nature thereof, on behalf of the Companies in their business of guaranteeing the fidelity of persons, guaranteeing the performance of contracts and
executing or guaranteeing bonds and undertakings required or permitted in any actions or proceedings allowed by law,
In Witness Whereof, and as authorlzed by a Resolution of the Board of Directors of the Companies on January 22, 2004, the Companies
have caused these presents to be signed by its Assistant Vice President and its corporate seals to be hereto affixed, duly attested by its Assistant
Secretary, Further, pursuant to Resolution of the Board of Directors of the Companies, the Companies hereby unambiguously affirm that they are
and will be bound by any mechanically applied signatures applied to this Power of Attorney.
Scott Sadowsky, Ass!stant Secretary
M. Ross Fisher, Assistant Vice President
STATE OFCONNECTICUT} SS.
Hartford
COUNTY OF HARTFORD
On this 31d day of March, 2008, before me personally came M. Ross Fisher, to me known, who being by me duly sworn, did depose and say: that
he resides In the County of Hartford, State of Connecticut; that he Is the Assistant Vice President of the Companies, the corporations described In and Which
executed the above Instrument; that he knows the seals of the said corporations; that the seals affixed to the said instrument are such corporate seals; that
they were so affixed by authority of the Boards of Directors of said corporations and that he signed his name thereto by like authorlly.
..........
t:~~
_
CERTIFICATE
/) ~,.-
/. _~~ CorM
j:?/)
/ .... _A."
<~
Scott E. Paseka
Notruy Public
My Commission Expires October 31, 20}2
I, the undersigned, Ass!stant Vice President of the Companies, DO HEREBY CERTIFY that the above and foregoing is a true and correct copy of
the Power of Attorney executed by said Companies, which is still in fun force effective as of
November 16 2012
'
Gary W. Stumper, Assistant Vice President
POA 2008
CALIFORNIA ALL·PURPOSE ACKNOWLEDGMENT
~
State of California
County of _-,=S:.:o.::n.::om=a_~_ _ _ _ _ _ _ __
On November 16, 2012 before me,
Date
}
Nancy L. Wallis, Notary Public
Here Insert Name and 11l1e of lhe OHicer
personally appeared ___-"'-S.::ta.::c:!..y.:.M.:..'-C::.l::.in::.t.:.o::.n_ _ _---,==;n;;;=""_~
Name(s) of Signer(s)
__________
be the persoi;ls) whose nameJS'l @'are-stlbscribed to the
~they executed the same in Ais/@/1I:lGir authorized
capacityOesf. and that by ~/tReir signaturejsy on the
instrument the person~or the entity upon behalf of
which the persontsr acted, executed the instrument.
true and correct.
Place Notary Sea! Above
Signature++'~~+~~~d:~2~_ _ __
---------------------opnONAL------~---------------Though the information below is not required by law, it may prove valuable' to persons relying on the document
and CQuld prevent fraudulent removal and reattachment of thIs form to another document.
Title or Type of Document: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _~_ _ _ _ _ _ _ _ _ _ _ __
Document Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Number of Pages: _ _ _ _ _ _ _ __
Capacity(iesl Claimed by Signer(s)
D
D
D
!lS
D
D
D
Individual
Corporate Officer - Title(s):
Partner - 0 Limited 0 General
Attorney in Fact
Trustee
Other: _ _ _ _ _ _ __
Signer's Name: _ _ _ _ _ _ _ _ _ _ _ _ _ __
D Individual
[JCorporate Officer - Title(s): _ _ _ _ _ _ _ __
[J Partner - 0 Limited 0 General
D Attorney in Fact
[JTrustee
[JOther: _ _ _ _ _ _ _ __
~~'@~~*~~~.v:g;g;g:;g
©2007 National Notary Association' 9350 De Solo Ave., P.O. 80x 2402 .Chatsworth, CA 91313-2402· www.Nallona!Notary.org Item #5907 Reorder:CaIiToll-Free 1-800-876-6827
SUBCONTRACTORS LIST
Project: ATHLETIC FACILITIES
.
Project No. 230043
Name of Bidder:
(6 Dr /;on '-:Tn c .
Bid Package No: 011200.24
rJ-t
Bid Package Description: Painting
~ 11
f- .'
Authorized Signature:
~?kh~ Uh ~
/
(A)
(8)
Licensed Name of
Subcontractor
Address of Office, Mill or
Shop
N(J)1Jl
(C)
Trade or Portion of Work
(0)
(E)
Contractor License No.
$$ Value of Work
[Submit within 24 hours of Bid
Opening per1l13.1 oflnstr. For
Bidders]
ISubmit within 24 hours of Bid
Opening per ~13.1 of lnstr. For
Bidders]
ISubmlt within 24 hours of Bid
Opening per1l13.1 oflns!r. For
Bidders]
[Submit within 24 hours of Bld
Opening per ~13.1 of tnstr. For
Bidders]
[Submit within 24110urs of Bid
Opening per1I13.1 of (nstr. For
Bidders]
Opening per1f13.1 oflnstr. For
Bidders)
Opening per1[!3.1 of Jnstr. For
Bidders]
[Submit withIn 24 hours of Bid
Opening per1l13.1 of Instr. For
Bidders]
Opening per 1113.1 of low. For
Bidders]
Opening per'i{13.1 of Instr. For
BiddersJ
Opening per ~13.1 of Inst!. For
Bidders]
[Submtt within 24 hours of Bid
Opening per 1113.1 oflostr. For
Bidders]
[Duplicate and attached additional page(s) as required.]
MoNTERE'f AVENUE Bff41~251-OB3s..o000
SUBCONTRACTORS LISi - SECTION 00225(J
MULTI PRIME-OCIP-AB 150& (07.11)
PAGE 1
DESERT COMMUNITY COLLEGE; DISTRICT
NON-COLLUSION DECLARATION
TO BE EXECUTED BY
BIDDER AND SUBMITTED WITH BID
)
STATE OF CA7lfORNIA
COUNTY OF
UrOYl¥=
PROJECT:
)
ATHLETIC FACILITIES
PROJECT NO: 230043
Bid Package No. 011200.24; Bid Package Description: Painting
I,
~~==-~~fi:f'~b,,=\'t2e.;:':V\,-l:h+-''':':-1'\:+=0'----_, being first duly sworn, depose and say that I am
:71
~KIUCSM .me.
~.
(Typed or Printed Nam
the -,-""",,~~--<.:=:ufL!!.lf<'-_ _ of
,the party submitting
I
(Bidder Name)
the foregoing Bid Pro sal ("the Bidder"). In connection with the foregoing Bid Proposal, the
undersigned declares, states and certifies that:
1. The bid is not made in the interest of, or on behalf of, any undisclosed person, partnership,
company, association, organization, or corporation. The bid is genuine and not collusive or sham.
2. The bidder has not directly Of indirectly induced or solicited any other bidder to put in a
false or sham bid.
3. The bidder has not directly or indirectly colluded, conspired, connived, or agreed with any
bidder or anyone else to put in a sham bid. or to refrain from bidding.
4. The bidder has not in any manner, directly or indirectly, sought by agreement,
communication, or conference with anyone to fix the bid price of the bidder or any other bidder, or to
fix any overhead, profit, or cost element of the bid price, or of that of any other bidder.
5. All statements contained In the bid are true.
6. The bidder has not, directly or indirectly, submitted his or her bid price or any breakdown
thereof, or the contents thereof, or divulged information or data relative thereto, to any corporation,
partnership, company, association, organization, bid depository, or to any member or agent thereof. to
effectuate a collusive or sham bid, and has not paid, and will not pay, any person or entity for such
purpose.
Any person executing this declaration on behalf of a bidder that is a corporation, partnership,
jOint venture, limited liability company, limited liability partnership, or any other entity, hereby
represents that he or she has full power to execute, and does execute, this declaration on behalf of
the bidder.
I declare under penalty of perjury under the laws of the State of California tl)at the~O~?OinQ.iS
true and correct and that this decfaration is executed on 1(- 2-D ,20lb., at !1!ff1(Llt!I'~r lill-,
California/i _ :/)/J '"'.
2!sM..V0:Z1
I
Signature
~/1.:vnA.
-I-- '.'
'i"M.'(/ Uh ~
-j 612
\1\fU\\nlAl A'V'enuC
(Address)
ABffi.. ~eIY\':::
fqame Printed or Typed
ULLL
ATHLETIC FACILITIes s#41-251-0835-0000
NON-COLLUSION AFFrDAvtT -SeCtIoN OOZ500
MULTI PRIME~OCIP'-AB 1506 (07~11)
CjCjLI_O\ 10
(Area Code and Telephone Number)
NON~COlLUS!ON AFFIDAVIT
PAGe 1
DRUG-FREE WORKPLACE CERTIFICATION
I,
---'.t,."-'~~-.,...!.\
~V\~()ra-:=:u-'le,,-,-,s,--,
\"'::""\..E..l.fA
(Print Name)
am the
_?->-;~~t~S.\.d"l-'
. . =e,,-,-,o,-,--\-_
of
(Title)
BORBONINCORPORATED
(Contractor Name)
I declare, state and certify to all of the following:
1.
I am aware of the provisions and requirements of California Government Code §§8350 et seq.,
the Drug Free Workplace Act of 1990.
2.
I am authorized to certify, and do certify, on behalf of Contractor that a drug free workplace will
be provided by Contractor by doing all of the following:
3.
A.
Publishing a statement notifying employees that the unlawful manufacture, distribution,
dispensation, possession or use of a controlled substance is prohibited in Contractor's
workplace and specifying actions which will be taken against employees for violation of
the prohibition;
B.
Establishing a drug-free awareness program to inform employees about all of the
following:
i.
The dangers of drug abuse in the workplace;
ii.
Contractor's policy of maintaining a drug-free workplace;
iii.
The availability of drug counseling, rehabilitation and ernployee-assistance
programs; and
iv.
The penalties that may be imposed upon employees for drug abuse violations;
C.
Requiring that each employee engaged in the performance of the Contract be given a
copy of the statement required by subdivision (A), above, and that as a condition of
employment by Contractor in connection with the Work of the Contract, the employee
agrees to abide by the terms of the statement.
D.
Contractor agrees to fulfill and discharge all of Contractor's obligations under the terms
and requirements of California Government Code §8355 by, inter alia, publishing a
statement notifying employees concerning: (a) the prohibition of any controlled
substance in the workplace, (b) establishing a drug-free awareness program, and (c)
requiring that each employee engaged in the performance of the Work of the Contract
be given a copy of the statement required by California Government Code §8355(a)
and requiring that the employee agree to abide by the terms of that statement.
Contractor and I understand that if the District determines that Contractor has either: (a) made
a false certification herein, or (b) violated this certification by failing to carry out and to
implement the requirements of California Government Code §§8355, the Contract awarded
herein is subject to termination, suspension of payments, or both. Contractor and I further
ATHLETIC FACILITIES 8#41·251-0283·0·0835·0000·621 0
DRUG·FREE WORKPLACE CERTIFICATE - SECTION 00630
MULTI PRIME - OCIP -AB 1506 (07.11)
DRUG-FREE WORKPLACE
CERTIFICATE
PAGE 1
understand that, should Contractor violate the terms of the Drug-Free Workplace Act of 1990,
Contractor may be subject to debarment in accordance with the provisions of California
Government Code §§8350, et seq.
4.
Contractor and I acknowledge that Contractor and I are aware of the provisions of California
Government Code §§8350, et seq. and hereby certify that Contractor and I will adhere to,
fulfill, satisfy and discharge all provisions of and obligations under the Drug-Free Workplace
Act of 1990.
I declare under penalty of perjury under the laws of the State of Califomia that all of the foregoing is
true and correct.
/1
Executed at
la
f /.
8.Jarza,. raVIi CA
!/':/....
\ J]dm"
r '
I"""l...
thisLday of
(City and St e)
20..L..,l.
(Signature)
(
CeollLa Utwa/~sl?res~
(Handwritten or Typed Nanle)
ATHLETIC FACILITIES 8#41 w251·0283-0-0835-0000-6210
DRUG-FREE WORKPLACE CERTIFICATE - SeCTION 00630
MULTI PRIME-OCIP- AB 1506 (07.11)
DRUG-FREE WORKPLACE
CERTIFICATE
PAGE 2
STATEMENT OF BIDDER'S QUALIFICATIONS
Bidder Name:
BorboVl ~CD'fFV'?dG?l
Project: ATHLETIC FACILITIES
Project No.: 230043
Bid Package No.: 011200.24
Bid Package Description: Painting
1.
Bidder's Organization
(..
1.1
Form of entity of Bidder, i.e., corporation, partnership, etc.Orr:oV'?tb b'-)f\..d
1.1.1 If a corporation, state the following:
State of incorporation: _C......,,-,-,..!.t:!...l-'_ _ _ _ _ _ _ _ _ _ _ _ _ _ __
r
D~te of incorporation:-I-i-'cl....1'-'W=<:...._:::-_7r:--:---:-_--,,-_ _ _ __
President/Chief Executive Officer:
Secretary:
SW,cq/~
'Fiore Vl·-b V1 0
TreasurerlChief Financial Officer:
1.1.2
reel It'o.... !vi OyUl t-eS
.
S+> C\ k) :6'oY'€J)/diVl.-{)
If a partnership, state the following:
Type of partnership, i.e., general partnership, limited partnership:
IV/It:
Names of all general partners, if any of the general partners are not natural
persons, provide the information for each such general partner requested by
Paragraphs 1.1.1, 1.1.2 and 1.1.4 as appropriate: _ _ _ _ _ _ _ _ __
1.1.3
If a proprietorship, state the names of all proprietors:
1.1.4
If a joint venture, state the following
Date of organization: _ _ _ _ _..J.N.>L.//c..L.J4='--_ _ _ _ _ _ _ _ _ __
Names of all joint venture members. For each member of the joint venture,
provide the information requested by Paragraphs 1.1.1, 1.1.2 and 1.1.3 for each
joint venture member, as appficable: _ _ _ _ _ _ _ _ _ _ _ _ _ __
ATH!..ET!C FACILITI5S Bfl41-251..oS3S..QOOO
STATEMENT Or QIJAI..!F!CATIONS - SECiJON 002700
MUI.TI PRIME..QCIP-AB 1506 (07.11)
STATEMENT OF QUALIFICATIONS
PAGE 1
ZGt J(S.
1.2
Number of years your organization has been in business as a contractor:
1.3
Number of years your organization has conducted business under its present name:
3lt?';):vf'
1.4
If your organization has conducted business under a name or name style different than
YOA//~~nization's present name, identify all prior name(s) or name style(s):
i
1.5
2.
Your organization's Federal Tax Identification Number:
q S- 30'61 '?3 X
I..icensing
2.1
California Contractors License:
3s 150)
Number:
Expiration Date:
'5-- '3 \.-
i <..\
Responsible Managing EmpioyeelOfficer:
-:::tee. Lui I ~'/.... .
License Classification(s): .......),C_·_-.,;:3:::;3=:.._ _ _ _ _ _ _ _ _ _ _ __
3.
2.2
Has a claim or other demand ever been made against your organization's California
Yes ~ No
Contractors License Bond?
If yes, on a separate attachment, state the following: (i) the name, address and
telephone number of each person or entity making claim or demand; (i1) the date of
each claim or demand; (Hi) the circumstances giving rise to each such claim or
demand; and (Iv) the disposition of each such claim or demand.
2.3
Has a complaint ever been filed against your organization's California Contractors
No
License with the California Contractors State License Board? __ Yes
If yes, on a separate attachment, state the followIng for each complaint: (i) the name,
address and telephone number of each person or entity making the complaint; (ii) the
date of each complaint; (iii) the circumstances giving rise to each such complaInt; and
(iv) the disposition of each such complaint, including without limitation, any disciplinary
or other action imposed or taken by the California Contractors State License Board as
a result of any such complaint.
1
Experience
3.1
Categories of work (other than m~nagementlsupervisifn). ~our organization typically
GI VIC
(:0·18. '"
performs with your own forces 1:'1 h' Vi
3.2
On a separate attachment, list all construction projects completed by your
organization in the past two (2) years and for each project identified, state: (i) a
general desoription of the work performed by your organization on the project; Oi} the
dollar value of the work performed or to be performed by your organization; (iii) the
project owner's name, name of the project owner's representative and the address and
telephone number of the owner and the project owner's representative; (iv) the project
architeot's name, address, telephone number and contact person; (v) the original
AruwmcFACIUTlES 8#41-251..0635·0000
STATEMENT OF QUAL1FICATIONS - SEc'noN 002700
MULTI PRIME--OCIP-AB 1506 (07.11)
STATgMENT OF QUALIFICATIONS
PAGE 2
contract price; (vi) the original completion duration; (vii) the final adjusted contract
price; and (viii) the actual completion duration.
3.3
4.
On a separate attachment, list all construction projects your organization has in
progress and for each project listed, state: (i) a general description of the work
performed by your organization on the project; (ii) the dollar value of the work
performed or to be performed by your organization; (iii) the project owner's name,
name of the project owner's representative and the address and telephone number of
the project owner and the project owner's representative; (iv) the project architecfs
name, address, telephone number and contact person; (v) percent presently complete;
and (vi) the current scheduled completion date.
Performance History
4.1
Claims and lawsuits (if you answer yes to any of the following, you must attach details).
4.1.1 Have any lawsuits or other administrative, legal, arbitration or other
proceedings, ever been brought or commenced against your organization or
any of its principals, officers or equity owners in connection with any
construction contract or construction project? _
Yes
No
If so, describe the circumstances, the amount demanded or other relief demand
and the disposition of each such lawsuit or other proceeding.
L
4.1.2
Has your organization ever filed a lawsuit or commenced other administrative,
legal or other proceedings in connection with any construction contract or
construction project? __ Yes ;)L No
If so, describe the circumstances, tlie amount demanded or other relief demand
and the disposition of each such lawsuit or other proceeding.
4.1.3
Are there any judgments, orders, decrees or arbitration awards pending,
outstanding against your organization or any of the officers, directors,
employees or principals of your organization? __ Yes ':I.. No
If so, describe each such judgment, order, decree or arbitiiTtiOii award and the
present status of the satisfaction or discharge thereof.
4.2
Has your firm or any predecessor to your firm, or any of its owners, officers, or partners
ever been found liable in a civil suit, or found guilty in a criminal action, for making any
false c/9jjifl or material misrepresentation to any public agency or entity?
Yes,6No
If"yes," provide details of each conviction on a separate attachment.
4.3
At any time during the last five years, has your firm or any predecessor to your firm, or
any of its owners, officers or partners ever been convicted of a crime involving any
federal, .;;9'te, or local law related to construction?
_YesANo
If "yes," 'provide details of each conviction on a separate attachment.
4.4
At any time during the last five years, has your firm or any predecessor to your firm. or
any of its owners, officers or partners ever been convicted of a federal or state crime of
fraud, theft or any other act of dishonesty?
Yes 'VNo
If"yes;,1r~vide details of each conviction on a separate attachment.
ATHLETIC FACIliTIES Bif41-251"'()83S..o000
STATEMl'lNT OF QUAUf'!CATfONS - SECTION 002100
MUL11 PRIME -oCIP -AS 1505 (07.11)
PAGE 3
4.5
Is your firm currently the debtor in a bankruptcy case?
_Yes~o
If 'yes," provide details on a separate attachment.
4.6
Was your firm, or any predecessor to your firm, in bankruptcy any time during the last
five (5) years? (This question refers only to a bankruptcy action that was not described
in answe~ to question 4-5, above).
-
Yes'~No
+"
If "yes," provide on a separate attachment.
4.7
In the last five (5) years, has your firm or any predecessor to your firm, been denied an
award of a public works contract based on a finding by a public agency that your
organization was not a responsible bidder?
Yes!?: No
If "yes,' provide. details on a separate attachment.
4.8
Within the last five (5) years, has there ever been a period when your organization had
employees but was without workers' compensation insurance or state-approved 5elfinsurance?
YeS){No
iPyes,' provide details on a separate attachment.
4.9
Has yq~urorganization ever refused to sign a construction contract awarded to it?
_Yes
No
'f so, on a separate attachment, state the following: (i) describe each such
contract; (ii) the owner's name, address, telephone number and contact person;
and (iii) the circumstances of your refusal to sign such contract.
4.10
Has your organization ever failed to complete a construction contract? _Yes
If so, on a separate attachment, state the following: (I) describe each such
contract; (iI) the owner's name, address, telephone number and contact person;
and (iii) the circumstances of your failure to complete such contract.
4.11
Has your organization ever been declared in default under a construction contract?
_ _ Yes -JLNo
If so, on a separate attachment, state the following: (i) describe each such
contract; (iI) the owner's name, address, telephone number and contact person;
and (iii) the circumstances of each such declaration of default.
4.12
Has any construction contract to which your organization was/is a party been
terminated for the convenience of the project owner? _YeS~No
If so, identify the project and project owner along with a description of the
circumstances under which the convenience termination occurred.
4.13
Has your organization been required to pay a premium of more than one percent (1%)
for a performance and payment bond on any project(s) on which your firm worked at
any time during the past three (3) years?
Yes
Y No
- - If 'yes7"Sfate the percentage that your organization was required to pay. You
may provide an explanation for a percentage rate higher than one percent (1%),
if you wish to do so.
:XNO
ATHLETIC FACIL1T!ES a#41-251wG835-0000
STATEMENT OF QUALIFICATIONS - SECTIQN 002700
MULTI PRIME-oCIP-A81506 (01.11)
PAGE 4
5.
4.14
Has a claim or other demand ever been asserted against any Bid Bond, Performance
Bond, or Payment Bond posted by your organization in connection with any
construction G,?~tract or your submittal of a bid proposal for a construction contract?
__ Yes ......,ANo
If so, an a separate attachment, state the following: (i) the name, address,
telephone number and contact person for each claimant; (ii) the date upon
which each such demand or claim was made; and (iii) the disposition of each
such demand or claim.
.
4.15
List all sureties (surety name, name of surety contact person, full address, telephone
and email of surety and surety contact person) that have issued bonds for your
organization during the last five (5) years, including the inclusive dates during which
each issued he bonds:
4.16
During the past five (5) years, has your organization ever been denied bond coverage
by a surety company, or has there ever been a period of time when your firm had no
surety bond if) place during a public construction project when one was required?
__ Yes -$.,.No
If "yes," on an attachment indicate the date when your organization was denied
coverage and the name of the company or companies which denied coverage;
and the period during which you had no surety bond in place.
4.17
At any time during the past five (5) years, has any surety company made any
payments on behalf of your organization to satisfy any claims made against a
performance or payment bond issued on your firm's behalf, in connection with a
construction project, either public or private?
Yes':;( No
If "ye?,»Qn a separate attachment set forth: (I) the amount of each such claim;
(Ii) the name and telephone number of the claimant, (iii) the date of the claim;
. (iv) the grounds for the claim; (v) the present status of the claim; (vi) the date of
resolution of such claim if resolved; (vii) the' method by which such was
resolved if resolved; (viii) the nature of the resolution; and (ix) the amount, if
any, at which the claim was resolved.
4.18
In the last five years has any insurance carrier, for any policy of insurance, refused to
renew the insurance policy for your firm?
_Yes --,2(NO
Owner Controlled Insurance Program Qualifications - Safety Requirements
In order to be a qualified bidder, the bidding contractor must meet minimum standards in order
to bid on the Project. The following qualification standards apply to ALL Bidding Contractors at
time of bid opening:
5.1
Workers Compensation Insurance Experience Modification Rating ("EMR"):
Current Year EMR
ATHleTiC FACILITIES 8#41-251-0835·0000
STATEMENT OF QUALIFICATIONS -SECTION 002700
MULTI PRIME-<lCIP-AB 1506 (07.11)
1.0
PAGES
5.2
Bidder has an average Workers' Compensatiq.n Experience Modification Rate (EMR) of
1.2£1 or less over the last five (5) years?
'.
+ Y~fS"NO,,, yO~~
firm is not qualified to bid this Project and your firm's Sid Proposal
will be deemed non-responsive.
5.3
Within the past five (5) years has your firm been subject to any Cal-OSHA citation(s)
for "serious" and/or "willful" safety violations?
_ _ Yes ~No
.
If "Yes," your firm is not qualified to bid this Project and your firm's Bid Proposal
5.4
Have you attached a copy of the Title Page and Table of Contents from your firm's
In
and Illness Prevention Program (IlPP)?
Yes __ No
If "No," your firm is not qualified to bid this Project and your firm's Bid Proposal
X
S.
Labor; Prevailing Wage and Apprenticeship Compliance
AUhe time of submitting this Statement of Qualifications, is your organization ineligible
to bid on or be awarded a public works contract, or perform as a sUbcontractor on a
public works contract, pursuant to either Labor Code §1777.1 or Labor Code section
6.1
§1777.7?
'\ /
_ _ Yes ~No
If "Yes," state the beginning and ending dates of the period of debarment:
6.2
Has there been more than one occasion during the past five (5) years in which your
organization was required to pay either back wages or penalties for your own
organization's failure to comply with California prevailing wage laws?
NOTE: This question refers only to your own organization's violation of prevailing wage
laws, not to ilations of the prevailing wage laws by a subcontractor.
Yes
No
- - If "yes," on a separate attachment, describe the nature of each Violation,
identifying the name of the project, the date of its completion, the public agency
for which it was constructed; the number of employees who were initially
underpaid and the amount of back wages and penalties that you were required
to pay.
6.3
During the past five (5) years, has there been more than one occasion in which your
own organization has been penalized or required to pay back wages for failure to
comply with the Federal Davis-Bacon prevailing wage requirements?
Yes
No
- - If "'jffs," on a separate attachment describe the nature of the violation,
identifying the name of the project, the date of its completion, the public agency
for which it was constructed; the number of employees who were initially
underpaid, the amount of back wages you were required to pay along with the
amount of any penalty paid.
::::1.-
ATHLEmC FACILITIES S#41H251..o835·0aoo
STATEIAENT OF QUAt..IFICATJONS - SeCTION 002700
MULTI PRIME...QCIP-AB 1506 (07.11)
PAGES
6.4
6.6
7.
At any time during the past five (5) years, has your organization been found to have
violated any provision of California apprenticeship laws or regulations, or the laws
pertaining t)(~e of apprentices on public works?
_ _ Yes
No
If "yes," provide the date(s) of such findings, and attach copies of the
Department's final decision(s).
References (Include name, contact person, telephone/telecopler and address for each
reference provided):
7.1
7.2
7.3
Trade References (three (3) minimum)
':t ~oaS-e &e Gl+hdlJ =€fA =¥
Bank References
7f elM S8> ~ q'rh:uJv~d"
.f:
Public Works Inspectors of Record (K-12 or community college projects)
'f, eli? Cl ,£Q.
ATHLETIC FAclunes B#41-251-0835~OOOO
srAIEMENT OF QUALIFICATIONS - SE;CTION 00i700
MUL11 PRIME -oCIP -AB 1506 (07.11)
£eg
cLHytP~
.r--
PAGE 7
7.4
8.
Owner references (three (3) minimum, preferably California K·12 school districts and/or
California community college districts)
Accuracy and Authority
The undersigned is duly authorized to execute this Statement of Bidders Qualifications under
penalty of perjury on behalf of the Bidder. The undersigned warrants and represents that
he/she has personal knowledge of each of the responses to this Statement of Bidder's
Qualifications and/or that he/she has conducted all necessary and appropriate inquiries to
determine the truth, completeness and accuracy of responses to this Statement of Bidder's
Qualifications.
The undersigned declares and certifies that the responses to this Statement of Bidder's
Qualifications are complete and accurate; there are no omissions of material fact or
information that render any response to be false or misleading and there are no misstatements
of fact in any of the responses.
Executed this
20 day of No~fIC
20.ll.at
//
S\A8U\f\
ATHLETlC f'ACJUTlI';$ e#41*251...uS35-0000
S'rATEMENl' OF QUAt..IFICATlONS - SeCTION 002700
MULTI PRIMt=:-aCIP ..A8150S (07.11)
BU\iJll\iLV7c\Y!L , (City
CAl·and State)
I
(SIgnature)
'tlOrentiVlO
(Type Name and TlUe)
PAGES
BORBON,INC.
PAitmNG CONl"RACTORS
General Contractor:
Project
Injury ~ Illness
Prevention Program
I.I.P.P.
(Safety Policies &: Procedures Manual)
7312 Walnut Avenue, Buena Park, California 90620 Phone # (714) 994-0170 Fax # (714)
994-0641
State License No. 351557
www.borbon.net
TABLE OF CONTENTS
1. SAFETY ORGANIZATION
Foreword
Acknowledgment of Receipt
Safety & Health Policy
Program Objectives
1
2
3
4
2. ASSIGNMENT OF RESPONIBILITY
Safety Coordinator
Supervisor's Safety Responsibility
Employee Responsibility
5
6-7
8
3. DISCIPLINARY POLICY
Introduction
Purpose
Circumstances leading to Disciplinary Action
Procedure
Employee Sanctions
Snpervision Sanctions
Summary
Supervisor's Disciplinary Action.
Asking me to overlook a Simple Safety Violation
Employee Warning
9
9
9
9
10
10
10
11
11
12
4. SAFETY ORIENTATION
New Employee Orientation
New Employee Checklist Instructions
Employee Safety Orientation Guideline
Safety Policy
Employee Responsibilities for Safety
Use of Equipment
First Aid Equipment
First Aid Responders
Employee Conduct
Alcohol and Drug Abuse
Hazard Communication.
Sanitation and Personal Hygiene
Special Chemical Hazards
Special Training
Personal Protective Equipment
Special Clothing
Code of Safe Practices .
Employee Acknowledgement Form
13
13
14
14
14
14
14
14
15
15
15
15
15
15
15
15
18
19
5. EMERGENCY PROCEDURES
Purpose
Objectives
Procedures
Emergency Action Plan .
Notification
Emergency Evacuation .
Emergency Coordinator's Responsibility
Emergency Contingency Plan
Different Type of Emergencies .
List of Emergency Equipment and Supplies (Form)
21
21
21
21
21
22
23
24
25-26
28
6. FIRE PREVENTION PROGRAM
Fire and Explosion Hazards and Prevention
Fire Extinguishers & Equipment
Employee Alarm Systems
Flammable Liquids
Scrap Receptacle- Type, Location and Use
Earthquakes
Fire and Emergency Plan Check list
Fire Extinguisher Inspection Record
29-31
32
33
34
35
36
38
39
7. ACCIDENT /LOSS REPORTING PROCEDURES
Purpose & Objectives .
Procedure
Serious Emergency Reporting
Call OSHA Reporting .
Handling Non-Serious Accidents
First Aid Treatment
Property / Equipment Damage
Vehicle Accident Reporting
Citizen! Public Accidents
Reporting Forms/ Format
Accident Investigation Report
"Employer's Report of Occupational Injury or Illness"
"Employee's Claim for Worker's Compensation Benefits"
Record Keeping
Employee Injuries
Vehicle, Property Damage, and Public Liability Reports .
First Aid Kit Requirements
First Aid Responders
OSHA Recordable Injuries
First Aid Log
40
40-41
41
42
42
42
42
43
43
43
43
43
43
44
44
44
45
46-48
49-51
53
8. ACCIDENT INVESTIGATION
Accident Investigation Procedures
Procedures for Investigating Accidents
9. SAFETY INSPECTIONS - HAZARDROUS CORRECTION PROCEDURES
Safety Inspections
Purpose.
Objectives
Procedures
Program Philosophy
Hazard Recognition (Inspections)
Hazard Correction
Imminent Danger
Safety Inspection Form .
Employee Participation .
Job/Task Observation Guide
Safety Inspection Form (Fonn)
Request for Corrective Action Items
Log of Corrective Action Items .
10. EMPLOYEE SUGGESTIONS
Introduction
Purpose.
Procedure
Employee Safety & Health Suggestion Form
54
55
62
62
62
62
62
63
63
64
64
64
65
66
68
69
70
70
70
71
11. SAFETY Training
Safety Training of Supervision
Safety Traiuing of Employees
Communicatiou of Safety & Health Matters
Safety Suggestions Program
Toolbox (Tailgate) Safety Meetings
Safety Training Outline / Guide .
Job Hazard Analysis
Job Hazard Analysis (Form)
12. HAZARD COMMUNICATION PROGRAM
Title and Purpose
Legal References
Site Coordinator
Hazard Determination and Disclosure
Labels and Other Forms of Warning
Employee Information and Training
Outside Contractors
Hazardous Non-Routine Tasks .
Storage of Hazardous Substances
72
72-75
75
75
76
77
84
85
86
86
86
86
87
87
88
88
89
Hazardous Wastes Disposal Procedures and Regulations .
Disclosure Procedure for Emergency Responders
Hazardous Chemical (Product) Inventory
List of Approved Vendors
13. MATERIAL SAFETY DATA SHEETS
Important Reference Information
Manufacturing Identification
Hazardous Ingredients .
Physical Data .
Fire and Explosion Hazard Information
Health Hazard Data
Reactivity Data .
Spill and Leak .
Special Protection Information
Special Precautions
89
90
95
96
97
97
97
97
97
97
98
98
98
98
14. CALIOSHA
CaI/OSI-IA Reports and Special Requirements
Special CaVOSHA Requirements
Posting Requirements .
Other Suggested Postings
Safety Information and Resources
138
138-139
140
140
141
15. BBP-MEDICAL EXPOSURE CONTROL PROGRAM
165-176
16. PERSONAL PROTECTIVE EQUIPMENT PROGRAM
181-188
17.RESPIRATOR SAFETY PROGRAM
207-241
18. SCAFFOLD SAFETY PROGRAM
242-253
19. FALL PROTECTION PROGRAM
254-263
20. HEAT INJURY PREVENTION PROGRAM
264-267
21. JOB SPECIFIC: SAFETY TRAINING, MSDS & PRODUCT DATA, JOB HAZARD
ANALYSIS, CONTACT LIST, COMPETENT PERSON AND DRUG TESTING
LETTER.
BorbonPaintin.g
.....
.
Project Name
Cars land Attraction & Ride
Description of Work
PaintIng
N
list ofCompleted Projects
.
.
Owner
Walt Disney
. .
.
.
'.
...
Construction Mgfl General Architect
Contractor
Clark
Borbon
Completion Contract Amount
Job No.
Date
2690
2012
$
2539
2012
LEED PROJECT
2,111,658.00
Imaqlneerlnq
575 Anton Blvd., Ste 100
Disney CA Adventure Theme Park
Anaheim, CA 92807
Costa Mesa, CA 92626
Los Angeles Trade Tech Center Painting
South Campus
Los Angeles
Community College
Taisei Construction
MDAJohnson
District
400 West Washington Blvd.
Anti Graffiti Coatings
Los Angeles, CA 90015
High Performance
6261 Katella Avenue #
210
Cypress, CA 90630
$
881,936.20
Coatings
E!astomeric Coatings
East Los Angeles College El &
Gl
Painting
Los Angeles
Community College
Swinerton Builders
2673
2012
$
406,920.00
2718
2012
$
439,868.00
2667
2012
$
474,840.00
District
865 S. Figueroa #3000
Los Angeles, CA 9007l
1301 Avenida Cesar Chavez
Monterey Park,CA 91754
Valley Region Span K-S
Painting
Los Angeles Unified
McCarthy
W. Bledsoe Street
Sylmar, CA 91342t
Anti Graffiti
School District
20401 SW Birth St
Newport Beach, CA
92660
GTE Middle School
Painting
Long Beach
McCarthy
1951 Cherry Avenue
Signal Hill, CA90755
Unified School
CLAC # 1 Phase 2
Los Angeles Unified
20401 SW Birch St
Newport Beach, CA
92660
Hensel Phelps
1600 W. Imperial HWY Box 175
School District
18850 Von Karman, Suite 100
Valley Region High School No.
Granada Hills, CA 91344
9900 N Painting
5
1001 Arroyo Avenue
2011
$ 2,149,753.00
2658
2011
$
2596
2011
$ 1,013,843.00
2567
2011
$
2694
2011
$
Irvlne,CA 92612
4
10445 Balboa Blvd.
Valley Region High School No.
2615
9960 N Anti Graffiti
LAUSD
Hensel Phelps
333 S. Beaudry
Avenue
Los Angeles, CA
90017
Los Angeles Unified
School District
18850 Von Karman Ave.,
Ste. 100
734,749.00
Irvine, CA 92612
Turner Construction
Martinez
Architects, Inc.
333 S. Beaudry
Avenue
Ritz Carlton & Marriot
Conference Center at LA lIVE!
7177 Exterior eMU Sealer Los Angeles, CA
90017
Olympic &
peL Construction
Painting
GeorgiaPartners, LLC
930 S. Georgia Street
Intumescent Fireproofing 714 Olympic Ste 300
San Fernando,CA 91340
los Angeles
443,820.00
Los Angeles, CA
90015
Ontario City Hall
Painting
303 East "B" Street
High Performance Coatings
Ontario, CA 91764
Gensler
City
of Ontano
Turner Construct/on
289,101.00
.
.
Borbonpain.tinglVlist.ofCompletedProjects
. ....
Description of Work
Project Name
..
.
.. . . .
Owner
.
Construction Mgr/ General Architect
Borbon
Contractor
Job No.
Concerto lofts
09900-Painting
GTS 900 FLLC
Astant
DeStefano&
Partners
900 S. Figueroa Street
Elastomeric
Coatings/Special
9595 Wilshire Blvd.
Ste 100
Beverly HHls, CA
90210
9595 Wilshire Blvd.
445 E. Illinois
Beverly HHls, CA 90212
Chicago 60610
2620
Date
2010
$ 1,591,966.00
213-239-2700
Painting
LAUSD
Turner Construction
355 S. Grand Avenue
Floor 11
Los Angeles, CA
90071
Martinez/Kueh, Thomas
LLP
Kim
Project
No. 2577
2010
$
219,000.00
Painting
Pinner Construction
LAU5D
355 S. Grand Avenue 1255 S. Lewis St
Floor 11
Anaheim, CA 92805
Los Angeles, CA
90071
Project
No. 2466
2010
$
377,000.00
South Region Middle School No.2 Painting
3620 Gage Avenue
Bell,
CA 90201
LAUSD
355 S. Grand Avenue
Floor 11
Los Angeles, CA
90071
SJ Amoroso
Treta Design
275 E. Baker Streeet,
1055 Wilshire
Suite B Costa Mesa, CA Blvd.
Los
92626
Angeles, CA
90017
Thomas
Kim
Project
No. 2652
2010
$
577,000.00
Oscar De La Hoya Charter School
1114 S. Lorena Street
Los
Angeles, CA 90023
Green Dot Public
Schools 350 S. Fig
Suite 213
Los Angeles, CA
90071
Howard S. Wright
2121 Alton Parkway #150
Irvine, CA 92600
Jake Vigil
Project
No. 2618
2010
$
313,400.00
2602
2009
$
737,221.84
Thomas
Kim
Project
No. 2505
2009
$
804,000.00
Project
No. 2392
200B
$
249,000.00
Thomas
Kim
8/1/2008
$
320,000.00
Sara Coughlin Elementary
School Addition
11035 Borden Avenue
Pacoima, CA 91331
Ramona Opportunity High School
231 S. Alma Avenue Los Angeles,
CA 90063
Painting
Metro Goldline Extension
2420 Painting
East Cesar Chavez Los Angeles, CA Anti Graffiti
Concrete Sealer
90033
Los Angeles County Eastside Light Rail
Constructors
MTA
Central Region E5 #19
831 N. Bonnie Beach Place
Painting
LAUSD
Pinner Construction
Intumescent Fireproofing 355 S. Grand Avenue 1255 S. Lew',s St
Floor 11
Anaheim, CA 92805
Los Angeles, CA
90071
EI Camino Humanities
Painting
Byrd High School
9171 Telfair Avenue
Valley, CA 91352
Painting
Sun Anti Graffiti
Fireproofing
EI Camino
CW Driver
Community College 16007 Crenshaw Blvd.
District
Torrance, Ca 90506
16007 Crenshaw
Blvd
Torrance, CA 90506
LAUSD
355 S. Grand Avenue
Floor 11
Los Angeles, CA
90071
DJM Construction
1540 S. Lewis 5t
Anaheim,CA 90095
John Sack
(714) 399-3640
Rossetti
Architects
999 N.
Sepulveda,
Suite 100
EI Segundo,
CA 90215
.
-"
Borbonpainting· tv List of Completed Projects
,
.
Description of Work
Project Name
Owner
Construction Mgr/ General Architect
Borbon
Contractor
Job No.
700 N, Central Ave,
Glendale, CA 91203
818,246.3481
Gensler
Architects
Painting
801 Grand, LLC
Intumescent Fire proofing 310 Washington
Blvd, Marina Del
Rey, CA 90292
peL Construction
Contact: Ziad Khalid
Vantilberg,
Barnvard
&
Solderberg
2000 Avenue of the Stars
Painting
Howard S,Wright
1111 5, Grand Ave
Gensler
Luma Condos
1100 South Hope St
Painting
Olympic West parking Structure
1005 W, Chick Hearn Court
Painting
9960-High Performance
Coatings
Grand Lofts
801 S, Grand
LA Arena Land
Company,Inc
1100 5, Flower St.
Los Angeles, CA
90015
Entertainment, LLC
A Delaware Limited
Liability Company
C/O J,P, Morgan
Fleming Asset.
Mgmt.
522 Fifth Ave, 9th
NY,
floor
NY 10036
South Park,RPO LLC Howard S,Wright
1120 NW Couch Ste 1111 5, Grand Ave
600
Portland, OR 97209
Painting
South Park,RPO LLC
1120 NW Couch Ste
600
Portland, OR 97209
UCLA Sproul Hall
360 De Neve Drive
Painting
LAX- Remote Boarding MODS
Van Nuys Air
16781 Stagg Street
Nuys, Ca 91406
EVO Condos
Grand Avenue
Angeles, CA 90015
1111
.
$
887,000,00
2008
$
749,524,00
2007
$
510,000,00
2008
$
919,765,00
Jake Vigil
Borbon
No,2479
Steve
.'
Barrett
Project
No,2336
Project
NO, 2337
Ankrom
Moisan
Associates
Project
No, 2394
Architects
Howard S,Wright
11115, Grand Ave
Steve Thompson
(949) 567-1909
Project
No,2389
Sep-08
$ 2,223,779,00
University of
DJM Construction
California
1540 5, Lewis St
Dan Batiwalla (310( Anaheim,CA 90095
206-8364
John Sack
(714) 399-3640
Thomas
Kim
Project
No, 2490
2008
$1,157,606
Painting
Los Angeles World
Airports
1 World Way
Los Angeles, CA
90009
Project
No,2373
2006
$
Painting
Wall covering
City of Los Angeles Swinerton
Dept of Public Works 865 5, Figueroa
Los Angeles CA 90017
Steve
Barrett
Project
No, 2248
2004
$ 1,088,637.46
Los
Van
.
Date
2H Construction
2651 Walnut Ave
Signal Hill CA 90755
562-4B4-5567
Uberstudio
525,000,00
".
,
.
..BQrbonpainting rvlist of Completed Projects
Project Name
..
Description of Work
Owner
.
Construction MgrJ General Architect
Borbon
Completion
Contractor
Job No.
Date
'
.
Contract Amount
Remote Boarding Mods LAX
Painting
Los Angeles World
Airports
1 World Way
Los Angeles, CA
90009
2H Construction
2651 Walnut Ave
Signal Hill CA 90755
562-484-5567
Steve
Barrett
Project
No, 2373
Jul-06
UCLA Westwood Hospital
Replacement
603 Westwood Plaza
310.824.5053
AESS PROJECT
Painting
High Performance
Coatings
Water Repellent
Joint Sealants
WaH Covering
UC Regents of
University of Ca
720. Charles E.
Young Drive
Los Angeles CA
90095
Tutor- Saliba
Thomas
Kim
Project
No.2086
2006
$ 5,384,340,00
Jake Vigil
Project
No.2545
Start 1/2008
Jun-08
$ 1,615,000,00
Steven
2007
$ 1,001,298,00
15901 Olden St,
Sylmar, CA 91342
818.362,8391
Americana @ Brand
Painting
233 S. Central AVenue Glendale CA High Performance
Coatings
91204
Bemard's
Caruso
101 The Grove Drive
Los Angeles ca
90036
Symantec MFox Hills
6059 Bristol Parkway
Culver City, ca 90230
Borbon Project No. 2474
Painting
Fabric Wrapped Panels
Symantec
Corporation
2500 Broadway
#200
Santa Monica, CA
90404
De! Ammo Parking Structure
21519 C. Mardona
Torrance, CA 90503
Painting
Mills Corporation
Whiting Turner
1300 Wilson Ste 400 3,Corporate Ste 100
Arlington, VA 22204 Irvine,CA 91266
LAUSD New High School No.lO
2202 S. Figueroa #734
Painting
LAUSD
Clark Construction
355 S. Grand Avenue 3100 Bristol st. Ste 100
Floor 11
Costa Mesa, ca 92606
Los Angeles, CA
90071
los Angeles New Primary School #
5
los Angeles Unified
Painting
Intumescent Fireproofing School District
los Angeles Police Hedquarters
9962 Anti Graffiti
218 South Spring Street
9912 Painting
Webcor
550 S, Hope Street
DJM Construction
1540 S, Lewis St
Anaheim,CA 90095
John Sack
(714) 399-3640
$
549,418,91
Barrett
Project
No, 2474
Walker Parking Project
Consultants
No.2388
Jun~06
$
315,667.00
$
950,000,00
$
174,419,00
Project
NO. 2244
Cunningham
Group
Architecture
Thomas
Kim
Project
No,2217
Jun-05
City of Los Angeles
Dept of Public Works
2440
2010
Riverside County
ASR ConstructIon
Economic Dev. Agency
2665
$ 1,539,124.00
Fire Retardant
Intumescent Fireproofing
Thermal Sheriff Station
A!rport Blvd. & Polk Street
,Riverside, CA 92509
$
388,319.54
Borbon, Inc. References
...
.
..
,
.
.
,
....
. ..
,
Frazee Paint
.
.Pail'1t Vendors '.
V'
p' ....
..... ·.Istaamt.
.
.....
Sherwin-Williams
. ..
. ..
Gerardo
2366 S. Travers Avenue
Commerce, CA 90040
(213) 727-2861
Patrick Dowling
2020 E. Ora ngethorpe
Fullerton, CA 92831
(714)680-3800
Ernie Hernandez
80610rnagethorpe
Buena Park, CA 90621
(714) 818-3344
Frazee - $394,814
Vista - $1,310,114
Sherwin Williams - $239,078
.....
..
. . d·
. . . TrCl " e
" ."',.
. ·,··Pinl"lerConstructi()n
Irufl1erConstruction
.
. .. ... Whiting
.... - Turner .,...,.
. ... ...••. ... .... .. > ,
. . ... ,... , .
Jeff Dodds
3 Corp. Plaza Suite 100
Irvine, CA 92606
John Pinner
1255 S. Lewis Street
Anaheim, CA 92805
Beverly King
555 W. 5th Street 37th Floor
(949) 836-0800
(714) 490-4000
(213) 891-3000
Bol1ding & SuretyJnforIl1at~on:
~llsu~al1ce(jaf!i~t§tAg~11~}I1~()r1Il~~iol1
The Hartford Fire Insurance Company
KPDlnsurance Services
Contact:
Dixon Wright
Business Address:
Contact:
Dawna Brosius, Commercial Account Manager
Business Address:
33 New Montgomery Street, 7th Floor
San Francisco, Ca 94104
Business Phone:
415.836.4858
1 lincoln Center, Suite 200
10300 SW Greenburg Road
Pordand, OR 97223
Business Phone:
503.892.0550
Business Fax:
800.929.0191
WelJsFargo ofCalifOrl1iail1SUrilnCe Services,Illc. ~Broker
Contact:
Stacey M. Davis
Business Address:
1039 N. McDowell Boulevard, Suite A
Petaluma, California 94954
Business Phone:
(707) 77H849
Business Fax:
(707) 769-1868
Gel1eralLiahility:
Hartford Underwriters Insurance Company
4utomobileLiahility:
Hartford Fire Insurance
'Bilnk&eferenc:e
J]ilnk ofthe West
Contact:
Edgar Morales
Business Address:
10230 S. Paramount Blvd.
Downey, CA 90241
Business Phone:
562.928.3361
Business Fax:
562.928.3369
. Excess/UmbreJJa Liability:
National Union Fire Insurance Company
Workers Compensation
Hartford Underwriters Insurance Company
BORBON, INC.
EDUCATION PROJECTS
.. Pomona College Mason Hall
.. Prairie Vista Middle School
It-
Ramona Opportunity High School
~
Rio Hondo College Central Plant
.. Roosevelt Elementary School Modernization
.. Saddleback College BGS Building
.. San Pedro High School New Gymnasium
.. Santa Ana College Physical Education Building
.. UCLA Engineering Building
.. UCLA Geology Building
.. UCLA Hedrick Hall
.. UCLA Kinsey Hall
.. UCLA Sproul Hall Dormitories
.. University of La Verne Abraham Campus Center
II<
Valley Region Early Education Center # 1
.. Warren High School Science Building
.. 333 Beaudry - Los Angeles Unified School District Headquarters
.. Byrd High School
.. Cabrillo Elementary School
.. California State University, Fullerton, Student Recreation Center
.. California State University, Northridge, Science Building 5
.. California State University, San Bernardino, Palm Desert Campus
.. Caltech Annenburg 1ST
.. Central Los Angeles Learning Center # 1
BORBON, INC.
• Chaffey College Main Instructional Building
• Cypress College Administration & Book Store
• Dana Middle School
.. Edison High School Modernization
~
EI Camino College Humanities Building
• Golden West College Health Sciences Building
• Gualberto J. Valadez Middle School
• Hawthorne Middle School
• Heritage High School
• Irvine Valley College Performing Arts Center
• Laguna Hills High School Modernization
• Loma Linda University Complex
• Los Angeles City College Child Development Center
• Los Angeles Mission College Child Development Center
• Los Angeles Mission College Parking Structure A
• Los Angeles Southwest College Technical Education Building
• Los Angeles Trade Technical College Child Development Center
• Louis Vandermolen Elementary School
• Miguel Contreras High School
• Murrieta Mesa High School
Step Up on Vine
Painting
1057 Vine Street
2811
$
79,000.00
2820
$
254,000.00
2769
$
793,210.00
1075 Hamilton Road
Duarte, CA 91010
Northridge Hospital
Shangri- La
Painting
Clark Construction
8200 Reseda Blvd.
Northridge, CA 91328
Project Manager:
DisneyGC3 Project
Painting
. Project Manager:
Dorsey High School
Paints & Coatings
Pinner Construction
2784
$
246,500.00
Painting
McCarthy Building, Co.
2753
$
263,525.00
2744
$
652,240.00 OSHPD
2066
$
922,000.00 OSHPD
2633
$
824,430.00
2664
$
234,508.00
3537 Farmdale Avenue
Paramount High School Phase V
14429 S. Downey Ave.
20401 S.W. Birch Street,Suite 300
Paramount, CA 90723
Newport Beach, CA 92660
Kaiser Anaheim HSB
3400 E. La Palma Avenue
Anaheim, CA 92807
Painting
High Performance
949-951-8383
Hensel Phelps
18850 Von Karman Ave., Ste. 100
Irvine, CA 92612
Santa Monica Orthopedic Hospital
Painting
Kaiser Ontario Hospital & HSB
Painting
Tutor- Saliba Corporation
15901 Olden Street
Sylmar, CA 91342
818-362-8391
Whiting Turner
2295 S. Vineyard
Anti-Graffiti Coatings
3 Coprorate, Suite 100
Ontario, CA 91761
Water Repellents
Irvine, CA 91266
131116th Street
Santa Monica, CA 90404
1
Building, Co.
20~01 S.W. Birch Street, Suite 300
302 West Huntington Drive
Arcadia, CA 91007
07190"Anti Graffiti Coatings
09860-Water Repellents
07920-Sealant/Caulking
Valley Region High School No.9
09900-Painting
Tuner Construction
lS020 W. Saticoy Street
Van Nuys, CA 92405
09960-Anti Graffiti Coatings
09980-Concrete Floor Sealers
1900 S. State College # 200
Anaheim, CA 92806
South Region Elementary School No.9
Painting
Sundt Construction
2777 Willow Place
1660 Hotel Circle N. Suite 400
South Gate, CA 90280
San Diego, CA 92108
Rancho Mirage High School No.4
9900-Painting
McCarthy
Ramona Rd & DaVall Rd
07900-Sealants/Caulking
20401 SW Birch St
2612
$
460,000.00
2733
$
165,000.00
2705
$
889,593.00
2670
$
74,000.00
Rancho Mirage, CA
Metro Pomona Atlantic Parking Structure
Painting
Klorman
255 South Atlantic Blvd.
Los Angeles, CA
Anti Graffiti
Water Repellent
23047 Ventura Blvd.
Woodland Hills, CA 91364
LASWC Middle College High School
B~rI'1ards Bros.
2737
$
184,000.00
1600 W. Imperial HWY # 172
Alaska Airlines
555 First Street
San Fernando, CA 91340
Hensel Phelps
18850 Von Karmen Ave., Ste. 100
Irvine, CA 92612
2742
$
326,945.00
2594
$
361,896.00
7101 West Imperial Highway
South Region Elementary School No.4
Painting
Pinner Construction
8929 Koffman Street
South Gate, CA 90280
Fireproofing
1255 S. Lewis St
Anaheim, CA 92805
2
Central Region ES #22
Painting
Hensel Phelps
13150 Bluff Creek Drive
9960-Anti Graffiti
Playa Vista, CA 90094
Concrete Floor Sealers
Irvine, CA 92612
Central Region Elementary School No. 20
Painting
Hensel Phelps
9960-Anti Graffiti
Concrete Floor Sea lers
Irvine, CA 92612
leuzinger High School
Pankow Builders
4118 Rosecrans
Lawndale, CA 90266
3280 E. Foothill Blvd., Ste 100
Pasadena, CA 91107
Cal Poly Pomona College of Business
Painting
CW Driver
3801 West Temple Avenue
Pomona, CA 91768
Exterior Texture Coatings
Multi Color Interior Coatings
Epoxy Coatings
Water Repellents
4200 Concours #350
Ontario, CA 91764
Cal State University Northridge Student Rec
Center
18111 Nordhoff Street
468 N. Rosemead Blvd
Pasadena, CA 91107
laguna Niguel City Halll Phase II
C.W. Driver
CW Driver
2730
$
248,000.00
2724
$
243,100.00
2736
$
183,950.00
2692
$
358,800.00
2684
$
359,100.00
2710
$
159,850.00
2707
$
1,550,000.00
Irvine, CA 92612
Kaiser Anaheim CUP 8< Hospital
Hensel Phelps
3400 East La Palma
Anaheim, CA 92807
Irvine, CA 92612
3
Ql
'iL
~r[""l'rC
~,~~~
Kaiser Ontario Hospital
Painting
Whiting Turner
2295 S. Vineyard Avenue
Anti Graffiti
' 3.Corporate Ste 100
Ontario, CA 91761
Water Repellents
Irvine,CA 91266
Methodist Hospital
Painting
McCarthy
302 W. Huntington Drive
Sealant-Caulking
20401 SW Birch St
Arcadia, CA 91007
Anti Graffiti
2633
$
824,430.00
2634
$
811,000.00
2647
$
195,000.00
Water Repellents
UCLA Olive View Medical Center
Painting
McCarthy
14445 Olive View Drive
Sealant-Caulking
20401SW l3irch St
Sylmar, CA 91342
San Gorgonio Memorial Hospital
ProWest
2688
$
182,000.00
Emma Construction
2502
$
71,000.00
600 N. Highland Springs Ave
Banning CA 92220-3090.
LA Mission College Child Development Center Painting
13356 Elridge Avenue
Water Repellents
Sylmar, CA 91342
4
Central lA Area New Middle School #1
Pinner Construction
6506 Union Avenue
1255 S. Lewis St
Los Angeles, CA
Anaheim, CA 92805
LA live! Conference Center BOH
Painting
PCl
1015 S. Cherry St
Elastomeric Coatings
70()N. Central Ave.
Anti Graffiti
Water Repellents
Glendale, CA 91203
Painting
Bernards
los Angeles Southwest Middle College High
School
1600 W. Imperial Highway #172
~n~i Gr~ffiti: Permashield Base 555 First Street
los Angeles, CA 90047
Aqua Seal MA12
San Fernando, CA 91340
USC John McKay Center
Painting
Tutor- Saliba Corporation
2270
$
502,700.00
2622
$
535,192.00
2737
$
184,000.00
2738
$
302,000.00
remlum
940 W. 35th Street
15901 Olden Street
Sylmar, CA 91342
818-362-8391
5
o
81
r~r'iES+IilJ
e~~~'J;
Metro Pomona Altlantic Parking Structure
K10rman Construction
255 S. Atlantic Blvd.
23047 Ventrua Blvd.
Los Angeles, Ca
Woodland Hills, CA 91364
Pomona College South Campus Parking Sturcture
Whiting Turner
295 E. First Street
3 Corporate Park, Suite 100
Claremont, CA 91711
Irvine, CA 92606
Civic Park
99113-Exterior Painting
Pankow
227 N. Spring Street
99123-Interior Painting
3280 E. Foothill
99623-Anti- Graffiti
Pasadena, CA 91107
2670
$
74,000.00
2693
$
195,170.00
2752
$
37,500.00
$
359,100.00
9960-High Performance
los Angeles Harbor College S.A.I.I..S. project 9900-Painting
1111 Figueroa Place
Wilmington, CA 90744
98433-WaliCovering
99623-Anti- Graffiti
Bernards
23461 S. Pointe Dr. # 300
Laguna Hills, CA 92653
40120-Masomy Cleaing
Cal State University Northridge
18111 Nordhoff Street
71900-Water Repellent
09910-Painting
99623-Anti-GraffitijWater
97209-Wallcovering
79200-Cauliking and Sealents
C.W. Driver
468 N. Rosemead Blvd.
Pasadena, CA 91107
626-351-8800
99618-Elastomeric coatings
78123-Intumescent
99613-Epoxy Coatings
6
06/06/2012 10:25 FAX 714 994 0641
BORBON INC
~001
CA.1ia"
Siale Of California
CONTRACTORS STATE LICENSE BOARD
Consumer-"
ACTIVE UCENSE
Mtairs
,-. ....." 351557
E<Ow
CORP
, "".""',-. BORBON INCORPORATED
""''''''''''''''' 05/31/2014
www.cslb.ca.gov
,
"-
~~
""
,,~~;:-
~
~y
~
j'- -
::"":I,,,,,~, "!«~L~0'}n0At
~,mlllnH~~i ,~,r%f "~.im~~~ ~~~~~c~:~,,::!:~g_
Name
Address
Telephone
WLC Architects
10470 Footill Blvd
Rancho Cucamonga, CA 91730
909.987.0909
Gensler
2500 Broadway Ste 300
310.449.5600
Perkins & Will
617 West
Street Ste 1200
213.270.8400
HMC Architects
2601 Main St 100
Irvine, CA 92614
909.567.1833
PJHM Architects
647 Camino De Los Mares
San Clemente, CA 92673
949.496.6191
rh
1.
Name:
Moreno Valley Unified School District
Address:
25634 Allesandro Blvd. Moreno Valley CA
Telephone:
909.485.5600
Contact:
Purchasing at above Number
Scope of Work:
Painting of Moreno Valley HS #2
Amount:
$ 330,000.00
2. Name:
Los Angeles Unified School District
Address:
355 S. Grand Avenue Suite 100, Los Angeles CA
Telephone:
818.956.0533
Contact:
Scope of Work:
Painting of Misc. LAUSD Schools
3. Name:
Newhall Unified School District
Address:
25375 Orchard Village Rd. Ste 20, Newhall CA
Telephone:
661.286.2200
Contact:
Scope of Work:
Painting of Oak Hills Elementary School
Amount:
$123,400.00
4. Name:
Magnolia Unified School District
Address:
2705 W. Orange Avenue, Anaheim CA
Telephone:
714.761.5533
Contact:
Scope of Work:
Painting of Pyles & Salk Elementary Schools
Amount:
$ 130,000.00
5. Name:
ABC Unified School District
Address:
16700 Norwalk Blvd., Cerritos CA
Telephone:
562.926.5516
Scope of Work
Painting of Misc Sites
Amount:
$ 259,000.00
6. Name:
Centinela Valley Unified School District
Address:
14901 S. Inglewood Ave, Lawudale CA
Telephone:
310.263.3250
Scope of Work:
Painting of Hawthome High School
Amount:
$ 231,200.00
Southern California Painters & Decorators
Labor Management Cooperation Committee
1155 Corporate Center Dr.• Monterey Park, CA 91754
(626) 844-1040
FAX (626) 798-0959
June 21, 2012
To whom it may concern:
RE: Borbon Inc.
Borbon Inc. is currently signed to the Painters and Allied Trades District
Council #36 master labor agreement 2010 - 2013 and has been a signatory
contractor in good standing since January 1975.
As of this date the Borbon Inc, is current with their employee to the trust funds
through the month of April 2012. Further review of our records reveal that their
state contractors license and worker compensation insurance are also current.
If you have any questions or if I can be of any further assistance please feel
free to call me.
Sincerely,
,aY4?~c/
Wileyz~kF~
Administrator
statuslettelllXX
Check a License - License Detail - Contractors State License Board
~
DEPARTMENT OF CONSUMER AFFAIRS
U~.
Contractors State License Board
Page 1 of 1
Contractor's license Detail - License # 351557
&
DISCLAIMER: A license status check provides information taken from the CSL8 license database. Before
relying on this Information, you should be aware of the following limitations•
..w CSLB complaint disclosure IS restricted by law (B&P 7124.6) If this entity is subject to pubUc complaint disclosure, a !ink
for complaint disclosure will appear below. Click on the link or button to oblain complaint and/or legal action Information .
.»
Per B&P 7071.17 , only construction related civil judgments reported to the CSl8 are disclosed.
.,;". Arbitrations are not listed unless the contractor fails to comply with the terms of the arbitration,
"»'
Due to workload, there may be relevant information that has not yet been entered onto the Board's license database,
License Number
Business Information
351557
Extract Date 2/5/2013
====:-::::--------------BORBON INCORPORATED
Business Phone Number: (714) 994-0170
-=-=____________
________
7312 WALNUT AVE
-'B""U,ENA P~!3J$1 CA 9_0620'-_ _ _ _ _ _ _ _ __
J~[l.~~
£qP.91~!!Pll,
__________________ ,________ ,_, _ _,_",_
02f1_5/19Z?
Issue Date
_ _ _ _-"05131120-'_4'---_ _ _ _ _ _ _ _ _ _ _ _ _ _ __
License Status
ACTIVE
This license is current and active. Allinfonnation below should be reviewed.
CLASS
Classifications
DESCRIPTION
-_..._---_.. _---C33
PAINTING AND DECORATING
CONTRACTOR'S BOND
This license filed a Contractor's Bond with
HARTFORD FIRE INSURANCE COMPANY.
Bond Number: 57BSBEI3979
Bond Amount: $12,500
Effective Date: 01/01/2007
Bonding
Contractor's Bond History
BONO OF QUALIFYING INDIVIDUAL
1.
This license filed Bond of Qualifying Individual number 57B88080379 for WILCOX
JOE KENNETH in the amount of $12,500 with HARTFORD FIRE INSURANCE
COMPANY.
BOl's Bond History
WORKERS' COMPENSATION
This license has workers compensation insurance with
FEDERAL !NSURANCE COMPANY
Workers' Compensation
Polley Number: 52WEQT2226
expire Date: 01/01/2014
Workers' Compensation History
Personnel listed on this license (current or disassociated) are !isted on other licenses,
Personnel List
Other Licenses
Conditions of Use I Privacy Policy
Copyright © 201 0 State of California
https:/1www2.cslb.ca.gov/OnlineServices/CheckLicenseIIfLicenseDetail.aspx?LicNum=3 51... 2/5/2013

Athletic Facilities - Borbon Inc painting

Transcription

Similar documents

After Party Flyer

Be Strong Brochure - Youth Over Violence

Friday, May 6, 2016 At Luminarias Restaurant

this PDF - UNLV Libraries Digital Collections

What is Budokan?

Free parking ! ~ Free event ! ~ SNAP / EBT accepted !

City Year #InstaGallery

Every Day Counts in Improving Mobility: A l d B id C i Every Day

Kightlinger, Jeff 092214

T R A V E L